Fluor Corporation
UNITED STATES SECURITIES AND EXCHANGE COMMISSION
Washington, DC 20549
FORM 10-Q
(Mark One)
| |
|
|
| þ |
|
QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934
|
For the quarterly period ended September 30, 2005
OR
| |
|
|
| o |
|
TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934
|
For the transition period from to
Commission File Number: 1-16129
FLUOR CORPORATION
(Exact name of registrant as specified in its charter)
| |
|
|
| Delaware
|
|
33-0927079 |
|
|
|
|
| (State or other jurisdiction of
|
|
(I.R.S. Employer I.D. No.) |
| incorporation or organization) |
|
|
One Enterprise Drive, Aliso Viejo, CA 92656
(Address of principal executive offices)
(Registrants telephone number, including area code)
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by
Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for
such shorter period that the registrant was required to file such reports), and (2) has been
subject to the filing requirements for at least the past 90 days. Yes þ No o
Indicate by check mark whether the registrant is an accelerated filer (as defined in Rule 12b-2 of
the Exchange Act). Yes þ No o
Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the
Exchange Act). Yes o No þ
As of October 31, 2005, there were 86,824,746 shares of common stock outstanding.
FLUOR CORPORATION
FORM 10-Q
September 30, 2005
1
PART I: FINANCIAL INFORMATION
Item 1. Financial Statements
FLUOR CORPORATION
CONDENSED CONSOLIDATED STATEMENT OF EARNINGS
Three Months Ended September 30, 2005 and 2004
UNAUDITED
| |
|
|
|
|
|
|
|
|
| $ in thousands, except per share amounts |
|
2005 |
|
|
2004 |
|
| |
REVENUES |
|
$ |
3,418,525 |
|
|
$ |
2,362,670 |
|
|
|
|
|
|
|
|
|
|
COSTS AND EXPENSES |
|
|
|
|
|
|
|
|
Cost of revenues |
|
|
3,237,647 |
|
|
|
2,257,972 |
|
Corporate administrative and general expense |
|
|
25,112 |
|
|
|
32,888 |
|
Interest expense |
|
|
3,853 |
|
|
|
3,734 |
|
Interest income |
|
|
(5,551 |
) |
|
|
(4,809 |
) |
| |
|
|
Total Costs and Expenses |
|
|
3,261,061 |
|
|
|
2,289,785 |
|
| |
|
|
|
|
|
|
|
|
|
|
|
EARNINGS BEFORE TAXES |
|
|
157,464 |
|
|
|
72,885 |
|
INCOME TAX EXPENSE |
|
|
26,275 |
|
|
|
25,623 |
|
| |
|
|
NET EARNINGS |
|
$ |
131,189 |
|
|
$ |
47,262 |
|
| |
|
|
|
|
|
|
|
|
|
|
|
EARNINGS PER SHARE |
|
|
|
|
|
|
|
|
BASIC |
|
$ |
1.54 |
|
|
$ |
0.58 |
|
| |
|
|
DILUTED |
|
$ |
1.51 |
|
|
$ |
0.57 |
|
| |
|
|
|
|
|
|
|
|
|
|
|
SHARES USED TO CALCULATE EARNINGS PER SHARE |
|
|
|
|
|
|
|
|
BASIC |
|
|
85,158 |
|
|
|
81,756 |
|
| |
|
|
DILUTED |
|
|
87,140 |
|
|
|
83,129 |
|
| |
|
|
DIVIDENDS DECLARED PER SHARE |
|
$ |
0.16 |
|
|
$ |
0.16 |
|
| |
|
|
See Accompanying Notes
2
FLUOR CORPORATION
CONDENSED CONSOLIDATED STATEMENT OF EARNINGS
Nine Months Ended September 30, 2005 and 2004
UNAUDITED
| |
|
|
|
|
|
|
|
|
| $ in thousands, except per share amounts |
|
2005 |
|
|
2004 |
|
| |
REVENUES |
|
$ |
9,198,234 |
|
|
$ |
6,640,374 |
|
|
|
|
|
|
|
|
|
|
COSTS AND EXPENSES |
|
|
|
|
|
|
|
|
Cost of revenues |
|
|
8,866,941 |
|
|
|
6,337,172 |
|
Corporate administrative and general expense |
|
|
90,873 |
|
|
|
93,665 |
|
Interest expense |
|
|
12,945 |
|
|
|
11,520 |
|
Interest income |
|
|
(16,155 |
) |
|
|
(12,485 |
) |
| |
|
|
Total Costs and Expenses |
|
|
8,954,604 |
|
|
|
6,429,872 |
|
| |
|
|
EARNINGS BEFORE TAXES |
|
|
243,630 |
|
|
|
210,502 |
|
INCOME TAX EXPENSE |
|
|
81,480 |
|
|
|
71,724 |
|
| |
|
|
NET EARNINGS |
|
$ |
162,150 |
|
|
$ |
138,778 |
|
| |
|
|
|
|
|
|
|
|
|
|
|
EARNINGS PER SHARE |
|
|
|
|
|
|
|
|
BASIC |
|
$ |
1.92 |
|
|
$ |
1.71 |
|
| |
|
|
DILUTED |
|
$ |
1.88 |
|
|
$ |
1.68 |
|
| |
|
|
|
|
|
|
|
|
|
|
|
SHARES USED TO CALCULATE EARNINGS PER SHARE |
|
|
|
|
|
|
|
|
BASIC |
|
|
84,617 |
|
|
|
81,302 |
|
| |
|
|
DILUTED |
|
|
86,095 |
|
|
|
82,599 |
|
| |
|
|
DIVIDENDS DECLARED PER SHARE |
|
$ |
0.48 |
|
|
$ |
0.48 |
|
| |
|
|
See Accompanying Notes
3
FLUOR CORPORATION
CONDENSED CONSOLIDATED BALANCE SHEET
September 30, 2005 and December 31, 2004
UNAUDITED
| |
|
|
|
|
|
|
|
|
| |
|
September 30, |
|
|
December 31, |
|
| $ in thousands, except share amounts |
|
2005 |
|
|
2004 * |
|
| |
ASSETS |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Current assets |
|
|
|
|
|
|
|
|
Cash and cash equivalents |
|
$ |
1,047,312 |
|
|
$ |
604,517 |
|
Accounts and notes receivable |
|
|
671,392 |
|
|
|
761,179 |
|
Contract work in progress |
|
|
942,895 |
|
|
|
1,076,687 |
|
Deferred taxes |
|
|
127,751 |
|
|
|
127,851 |
|
Other current assets |
|
|
120,042 |
|
|
|
153,080 |
|
| |
|
|
Total current assets |
|
|
2,909,392 |
|
|
|
2,723,314 |
|
|
|
|
|
|
|
|
|
|
Property, plant and equipment (net of accumulated
depreciation of $453,220 and $409,294,
respectively) |
|
|
549,046 |
|
|
|
527,808 |
|
Investments and goodwill |
|
|
196,972 |
|
|
|
162,225 |
|
Deferred taxes |
|
|
30,179 |
|
|
|
31,691 |
|
Pension assets |
|
|
165,514 |
|
|
|
187,455 |
|
Other |
|
|
372,562 |
|
|
|
337,064 |
|
| |
|
|
|
|
$ |
4,223,665 |
|
|
$ |
3,969,557 |
|
| |
|
|
LIABILITIES AND SHAREHOLDERS EQUITY |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Current liabilities |
|
|
|
|
|
|
|
|
Trade accounts payable |
|
$ |
865,627 |
|
|
$ |
722,910 |
|
Short-term debt |
|
|
|
|
|
|
129,940 |
|
Advance billings on contracts |
|
|
460,573 |
|
|
|
389,895 |
|
Accrued salaries, wages and benefits |
|
|
336,583 |
|
|
|
308,907 |
|
Other accrued liabilities |
|
|
186,706 |
|
|
|
212,329 |
|
| |
|
|
Total current liabilities |
|
|
1,849,489 |
|
|
|
1,763,981 |
|
|
|
|
|
|
|
|
|
|
Long-term debt due after one year |
|
|
347,663 |
|
|
|
347,649 |
|
Noncurrent liabilities |
|
|
490,786 |
|
|
|
522,135 |
|
|
|
|
|
|
|
|
|
|
Contingencies and commitments |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Shareholders equity |
|
|
|
|
|
|
|
|
Capital stock |
|
|
|
|
|
|
|
|
Preferred
authorized 20,000,000 shares
($0.01 par value); none issued |
|
|
|
|
|
|
|
|
Common authorized 150,000,000 shares
($0.01 par value); issued and outstanding
86,804,958 and 84,538,107 shares,
respectively |
|
|
868 |
|
|
|
845 |
|
Additional capital |
|
|
615,521 |
|
|
|
507,133 |
|
Unamortized executive stock plan expense |
|
|
(44,568 |
) |
|
|
(33,757 |
) |
Accumulated other comprehensive income (loss) |
|
|
(15,368 |
) |
|
|
2,970 |
|
Retained earnings |
|
|
979,274 |
|
|
|
858,601 |
|
| |
|
|
Total shareholders equity |
|
|
1,535,727 |
|
|
|
1,335,792 |
|
| |
|
|
|
|
$ |
4,223,665 |
|
|
$ |
3,969,557 |
|
| |
|
|
* Amounts at December 31, 2004 have been derived from audited financial statements.
See Accompanying Notes
4
FLUOR CORPORATION
CONDENSED CONSOLIDATED STATEMENT OF CASH FLOWS
Nine Months Ended September 30, 2005 and 2004
UNAUDITED
| |
|
|
|
|
|
|
|
|
| $ in thousands |
|
2005 |
|
|
2004 |
|
| |
CASH FLOWS FROM OPERATING ACTIVITIES |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Net earnings |
|
$ |
162,150 |
|
|
$ |
138,778 |
|
Adjustments to reconcile net earnings to cash provided
(utilized) by operating activities: |
|
|
|
|
|
|
|
|
Depreciation of fixed assets |
|
|
74,695 |
|
|
|
63,507 |
|
Amortization of intangibles |
|
|
1,615 |
|
|
|
958 |
|
Restricted stock amortization |
|
|
13,829 |
|
|
|
12,337 |
|
Taxes paid on vested restricted stock |
|
|
(9,184 |
) |
|
|
(5,909 |
) |
Deferred taxes |
|
|
896 |
|
|
|
4,330 |
|
Stock option tax benefit |
|
|
11,047 |
|
|
|
5,689 |
|
Retirement plan accrual, net of contributions |
|
|
(12,450 |
) |
|
|
24,174 |
|
Unbilled fees receivable |
|
|
(32,594 |
) |
|
|
(17,459 |
) |
Changes in operating assets and liabilities,
excluding effects of business acquisitions |
|
|
476,453 |
|
|
|
(195,986 |
) |
Gain on sale of real estate |
|
|
(14,618 |
) |
|
|
(12,866 |
) |
Equity in (earnings) loss of investees |
|
|
(13,655 |
) |
|
|
2,227 |
|
Other, net |
|
|
1,331 |
|
|
|
(2,501 |
) |
| |
|
|
Cash provided by operating activities |
|
|
659,515 |
|
|
|
17,279 |
|
| |
|
|
|
|
|
|
|
|
|
|
|
CASH FLOWS FROM INVESTING ACTIVITIES |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Capital expenditures |
|
|
(145,277 |
) |
|
|
(68,849 |
) |
Acquisition, net |
|
|
|
|
|
|
(33,000 |
) |
Investments, net |
|
|
(13,604 |
) |
|
|
2,358 |
|
Proceeds from sale of real estate |
|
|
45,049 |
|
|
|
59,688 |
|
Proceeds from disposal of property, plant and equipment |
|
|
17,020 |
|
|
|
16,655 |
|
Other, net |
|
|
(1,955 |
) |
|
|
(2,600 |
) |
| |
|
|
Cash utilized by investing activities |
|
|
(98,767 |
) |
|
|
(25,748 |
) |
| |
|
|
|
|
|
|
|
|
|
|
|
CASH FLOWS FROM FINANCING ACTIVITIES |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Proceeds from issuance of convertible debt |
|
|
|
|
|
|
330,000 |
|
Debt issuance costs |
|
|
|
|
|
|
(7,490 |
) |
Repayment of facilities financing |
|
|
|
|
|
|
(128,581 |
) |
Decrease in short-term borrowings |
|
|
(129,940 |
) |
|
|
(121,469 |
) |
Net proceeds from issuance of common stock |
|
|
41,820 |
|
|
|
|
|
Stock options exercised |
|
|
40,198 |
|
|
|
33,718 |
|
Cash dividends paid |
|
|
(41,477 |
) |
|
|
(39,975 |
) |
Other, net |
|
|
(1,293 |
) |
|
|
(506 |
) |
| |
|
|
Cash provided (utilized) by financing activities |
|
|
(90,692 |
) |
|
|
65,697 |
|
| |
|
|
Effect of exchange rate changes on cash |
|
|
(27,261 |
) |
|
|
7,819 |
|
| |
|
|
Increase in cash and cash equivalents |
|
|
442,795 |
|
|
|
65,047 |
|
Cash and cash equivalents at beginning of period |
|
|
604,517 |
|
|
|
496,502 |
|
| |
|
|
Cash and cash equivalents at end of period |
|
$ |
1,047,312 |
|
|
$ |
561,549 |
|
| |
|
|
See Accompanying Notes
5
FLUOR CORPORATION
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS
UNAUDITED
| (1) |
|
The Condensed Consolidated Financial Statements do not include footnotes and certain
financial information normally presented annually under accounting principles generally
accepted in the United States, and therefore should be read in conjunction with the
companys December 31, 2004 annual report on Form 10-K. Accounting measurements at interim
dates inherently involve greater reliance on estimates than at year-end. The results of
operations for the three and nine months ended September 30, 2005 are not necessarily
indicative of results that can be expected for the full year. |
| |
| |
|
The Condensed Consolidated Financial Statements included herein are unaudited; however, they
contain all adjustments (consisting of normal recurring accruals including certain contract
loss provisions during the nine months ended September 30, 2005) which, in the opinion of
the company, are necessary to present fairly its consolidated financial position at
September 30, 2005, its consolidated results of operations for the three and nine months
ended September 30, 2005 and 2004 and its consolidated cash flows for the nine months ended
September 30, 2005 and 2004. |
| |
| |
|
Certain 2004 amounts have been reclassified to conform with the 2005 presentation. |
| |
| (2) |
|
The components of comprehensive income, net of related tax, are as follows: |
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
|
Nine Months Ended |
|
| |
|
September 30 |
|
|
September 30 |
|
| $ in thousands |
|
2005 |
|
|
2004 |
|
|
2005 |
|
|
2004 |
|
| |
Net earnings |
|
$ |
131,189 |
|
|
$ |
47,262 |
|
|
$ |
162,150 |
|
|
$ |
138,778 |
|
Foreign currency
translation
adjustment |
|
|
16,474 |
|
|
|
4,978 |
|
|
|
(18,338 |
) |
|
|
2,227 |
|
| |
|
|
|
|
Comprehensive income |
|
$ |
147,663 |
|
|
$ |
52,240 |
|
|
$ |
143,812 |
|
|
$ |
141,005 |
|
| |
|
|
|
|
| (3) |
|
As the result of international embassy contract provisions recorded in the first quarter of
2005 and a $65 million charge during the second quarter of 2005 associated with the
unfavorable jury award on a project in the Cayman Islands, which represent foreign losses, the
companys ability to absorb foreign taxes incurred in high tax jurisdictions was significantly
diminished; accordingly, certain foreign earnings were subject to both U.S. and foreign taxes
without an offsetting foreign tax credit during the first half of the year. The set-aside of
the jury verdict and no-liability resolution of the Cayman Islands hotel project, along with
the settlement of the Hamaca Crude Upgrader project claims during the third quarter of 2005,
substantially reverse the foreign losses recorded in prior quarters and restore the companys
ability to absorb foreign taxes incurred in high tax jurisdictions. This coupled with the tax
benefit attributable to the foreign repatriation provision enacted under the American Jobs
Creation Act of 2004 (the Jobs Act) discussed further below gave rise to the low 16.7
percent effective tax rate in the current quarter. The effective tax rate for the nine months
ended September 30, 2005 returned to a more typical annualized level of 33.4 percent from the
effective tax rate of 64.1 percent for the six months ended June 30, 2005. |
| |
| |
|
On October 22, 2004, the Jobs Act was signed into law. Among its various provisions, the
Jobs Act creates a one-time incentive for U.S. corporations to repatriate certain qualified
foreign earnings by providing an 85 percent dividends received deduction, subject to
specific reinvestment guidelines and certain limitations. On December 21, 2004, the
Financial Accounting Standards Board (FASB) issued FASB Staff Position 109-2, Accounting
and Disclosure Guidance for the Foreign Earnings Repatriation Provision within the American
Jobs Creation Act of 2004 (FSP 109-2). FSP 109-2 allows companies additional time beyond
the
financial reporting period in which the Jobs Act was enacted to evaluate the effect of the
Jobs Act on a
|
6
FLUOR CORPORATION
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS
(CONTINUED)
UNAUDITED
| |
|
companys plan for reinvestment or repatriation of unremitted foreign earnings for the
purpose of applying Statement of Financial Accounting Standards (SFAS) No. 109,
Accounting for Income Taxes. |
| |
| |
|
On August 11, 2005, the companys Domestic Reinvestment Plan (the Plan) prepared pursuant
to the Jobs Act was approved by the companys Chief Executive Officer. The Plan was ratified
by the Executive Committee of the companys Board of Directors on August 29, 2005. |
| |
| |
|
On September 29, 2005, approximately $89 million was repatriated from certain foreign
subsidiaries of the company, including certain previously taxed income and the base year
amount as provided under the repatriation provision of the Jobs Act. The results of
operations for the three and nine months ended September 30, 2005 include a tax benefit of
$4.1 million attributable to the dividends received deduction net of the foreign tax credits
given up in exchange for such deduction. As the computation of the above tax benefit took
into account, among other things, the projected earnings and foreign taxes to be incurred by
the distributing subsidiaries for the full year of 2005, a true-up will be required at the
end of the year. |
| |
| |
|
In addition, the computation of the above tax benefit was based on the repatriation statute
enacted under the Jobs Act and a series of notices issued to date by the U.S. Treasury
Department and the Internal Revenue Service (IRS) in connection with such repatriation
provision. This tax benefit may be impacted by future law changes enacted by Congress or
the further guidance issued by the U.S. Treasury Department or the IRS. The impact of such
future changes will be reflected in the financial reporting period in which any such change
in law is enacted or becomes effective. |
| (4) |
|
Cash paid for interest was $14.3 million and $10.9 million for the nine months ended
September 30, 2005 and 2004, respectively. Income tax payments, net of receipts, were $70.7
million and $45.7 million during the nine-month periods ended September 30, 2005 and 2004,
respectively. |
| |
| (5) |
|
The company accounts for stock-based compensation using the intrinsic value method prescribed
by Accounting Principles Board Opinion No. 25, Accounting for Stock Issued to Employees, and
related Interpretations (APB 25), as permitted by Statement of Financial Accounting
Standards (SFAS) No. 123, Accounting for Stock-Based Compensation (SFAS 123).
Accordingly, compensation cost for stock options is measured as the excess, if any, of the
quoted market price of the companys stock at the date of the grant over the amount an
employee must pay to acquire the stock. All unvested options outstanding under the companys
option plans have grant prices equal to the market price of the companys stock on the date of
grant. Compensation cost for restricted stock is determined based on the fair value of the
stock at the date of grant. Compensation cost for stock appreciation rights and performance
equity units is determined based on the quoted market price of the companys stock at the end
of the period. |
| |
| |
|
In December 2004, the Financial Accounting Standards Board (FASB) issued SFAS 123-R,
Share-Based Payment (SFAS 123-R), which is a revision of SFAS 123. SFAS 123-R supersedes
APB 25 and amends SFAS 95, Statement of Cash Flows. Generally, the approach in SFAS 123-R
is similar to the approach described in SFAS 123. However, SFAS 123-R requires all
share-based payments to employees, including grants of employee stock options to be
recognized in the income statement based on their fair values. Upon adoption of SFAS 123-R,
pro forma disclosure is no longer an alternative. |
| |
| |
|
The provisions of SFAS 123-R apply to awards granted after the required effective date of
the statement, which is no later than January 1, 2006 for the company. Initial application
to existing
unvested stock option awards may be based on either a modified prospective method or a
modified retrospective method. The method of application selected by the company will |
7
FLUOR CORPORATION
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS
(CONTINUED)
UNAUDITED
| |
|
determine which, if any, previously reported operating results will be restated for
comparative purposes. Based on unvested options outstanding at September 30, 2005, the
adoption of SFAS 123-Rs fair value method will not have a material impact on results of
operations and will have no impact on overall financial position. |
| |
| |
|
Currently under APB 25, no compensation cost is recognized for unvested stock options where
the grant price is equal to the market price on the date of grant and the vesting provisions
are based only on the passage of time. Had the company recorded compensation expense using
the accounting method recommended by SFAS 123, net earnings and earnings per share would
have been reduced to the pro forma amounts as follows: |
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
|
Nine Months Ended |
|
| |
|
September 30 |
|
|
September 30 |
|
| $ in thousands, except per share amounts |
|
2005 |
|
|
2004 |
|
|
2005 |
|
|
2004 |
|
| |
Net earnings |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
As reported |
|
$ |
131,189 |
|
|
$ |
47,262 |
|
|
$ |
162,150 |
|
|
$ |
138,778 |
|
Stock option expense,
net of tax |
|
|
(334 |
) |
|
|
(5,027 |
) |
|
|
(1,588 |
) |
|
|
(7,672 |
) |
| |
|
|
|
|
Pro forma |
|
$ |
130,855 |
|
|
$ |
42,235 |
|
|
$ |
160,562 |
|
|
$ |
131,106 |
|
| |
|
|
|
|
Basic net earnings per share |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
As reported |
|
$ |
1.54 |
|
|
$ |
0.58 |
|
|
$ |
1.92 |
|
|
$ |
1.71 |
|
| |
|
|
|
|
Pro forma |
|
$ |
1.54 |
|
|
$ |
0.52 |
|
|
$ |
1.90 |
|
|
$ |
1.61 |
|
| |
|
|
|
|
Diluted net earnings per share |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
As reported |
|
$ |
1.51 |
|
|
$ |
0.57 |
|
|
$ |
1.88 |
|
|
$ |
1.68 |
|
| |
|
|
|
|
Pro forma |
|
$ |
1.51 |
|
|
$ |
0.51 |
|
|
$ |
1.86 |
|
|
$ |
1.59 |
|
| |
|
|
|
|
| |
|
In 2003, the company granted certain options providing for accelerated vesting if specific
market conditions were achieved. In the third quarter of 2004, those options became 100
percent vested because the average closing price of the companys common stock exceeded a
specified price for 20 consecutive trading days. As a result, the remaining compensation
cost for the fully vested options was treated as a pro forma option expense above for the
three and nine months ended September 30, 2004. |
| |
| |
|
The company has not historically considered retirement eligibility in determining
stock-based compensation expense, including expense associated with stock options and
restricted stock. The adoption of SFAS 123-R will require the company to assume the first
date on which an employee becomes eligible to retire in determining the amortization period
for future stock-based awards. For example, if the employee is eligible for retirement two
years from the date of grant, the amortization period will be no longer than two years
rather than the specified service period over which awards normally vest. Upon adoption of
FAS 123-R retirement eligibility will be considered in the determination of periodic expense
on a prospective basis for all future stock-based awards. Prior periods or amounts
previously recognized will not be adjusted or restated. Compensation expense associated
with awards granted in prior periods will continue to be recognized using historical
amortization practices. |
| |
| |
|
The impact of using retirement eligibility in determining stock option expense would have
been to decrease the pro forma adjustments by approximately 65 percent for the three and
nine month
periods ended September 30, 2005 and to decrease the pro forma adjustments by approximately
60 percent for the three and nine month periods ended September 30, 2004, with offsetting
increases in preceding years. The impact of using retirement eligibility to determine
amortization
|
8
FLUOR CORPORATION
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS
(CONTINUED)
UNAUDITED
| |
|
periods on previously recorded restricted stock amortization for the three and
nine month periods ended September 30, 2005 and 2004 would have been to increase restricted
stock amortization expense by approximately one-third. |
| |
| |
|
For the three and nine months ended September 30, 2005, recognized compensation expense of
$4.3 million and $13.8 million, respectively, are included in corporate administrative and
general expense related to restricted stock, compared with $4.1 million and $12.3 million
for the three and nine months ended September 30, 2004. |
| (6) |
|
Operations are organized in five industry segments: Oil & Gas, Industrial & Infrastructure,
Government, Global Services and Power. The Oil & Gas segment provides engineering and
construction professional services for upstream oil and gas production, downstream refining,
chemicals and petrochemicals markets. The Industrial & Infrastructure segment provides
engineering and construction professional services for manufacturing and life sciences
facilities, commercial and institutional buildings, mining, microelectronics,
telecommunications and transportation projects and other facilities. The Government segment
provides project management, engineering, construction, and contingency response services to
the United States government, which represents a significant customer. The Global Services
segment includes operations and maintenance, equipment and temporary staffing services and the
companys global procurement services business. The Power segment provides professional
services to engineer, construct and maintain power generation facilities. |
| |
| |
|
Through the second quarter of 2004, services provided by the Power segment were primarily
conducted through two jointly owned groups; Duke/Fluor Daniel, 50 percent owned partnerships
with Duke Energy, and ICA Fluor Daniel (ICA Fluor), 49 percent jointly owned companies
with Grupo ICA, a Mexican company. As the result of a shift in the markets served by and
the types of projects awarded to ICA Fluor, commencing in the third quarter of 2004, its
operating results and assets are included in the Oil & Gas segment. Prior periods have not
been restated for the change in segment classification of ICA Fluor. |
| |
| |
|
In July 2003, the company jointly announced with Duke Energy Corporation the decision to
dissolve the Duke/Fluor Daniel partnership as a result of the significant decline in the
construction of new power plants. The dissolution is not expected to have a material impact
on results of operations or financial position of the company. The dissolution is in
progress and is expected to be completed in 2005 as remaining project activities are
concluded. The company will continue to identify and pursue power generation opportunities
and future projects will be performed 100 percent by Fluor. |
| |
| |
|
In the first quarter of 2005, the company realigned its chemicals business line, which had
been part of the Industrial & Infrastructure segment, under the Oil & Gas segment. This
change was made to better match the needs for the large number of petrochemical projects
anticipated over the next few years with the Oil & Gas segments project support
infrastructure. All prior periods have been restated to reflect this change. |
9
FLUOR CORPORATION
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS
(CONTINUED)
UNAUDITED
| |
|
Operating information by segment is as follows for the three and nine months ended September
30, 2005 and 2004: |
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
|
Nine Months Ended |
|
| External Revenue |
|
September 30 |
|
|
September 30 |
|
| ($ in millions) |
|
2005 |
|
|
2004 |
|
|
2005 |
|
|
2004 |
|
| |
Oil & Gas |
|
$ |
1,447.5 |
|
|
$ |
1,000.4 |
|
|
$ |
3,844.4 |
|
|
$ |
2,360.7 |
|
Industrial & Infrastructure |
|
|
857.3 |
|
|
|
521.4 |
|
|
|
2,085.5 |
|
|
|
1,432.6 |
|
Government |
|
|
651.3 |
|
|
|
529.7 |
|
|
|
1,859.6 |
|
|
|
1,698.7 |
|
Global Services |
|
|
367.8 |
|
|
|
279.5 |
|
|
|
1,116.0 |
|
|
|
896.9 |
|
Power |
|
|
94.6 |
|
|
|
31.7 |
|
|
|
292.7 |
|
|
|
251.5 |
|
| |
|
|
|
|
Total external revenue |
|
|
$3,418.5 |
|
|
$ |
2,362.7 |
|
|
$ |
9,198.2 |
|
|
$ |
6,640.4 |
|
| |
|
|
|
|
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
|
Nine Months Ended |
|
| Operating Profit (Loss) |
|
September 30 |
|
|
September 30 |
|
| ($ in millions) |
|
2005 |
|
|
2004 |
|
|
2005 |
|
|
2004 |
|
| |
Oil & Gas |
|
$ |
84.1 |
|
|
$ |
51.0 |
|
|
$ |
188.0 |
|
|
$ |
111.7 |
|
Industrial & Infrastructure |
|
|
43.5 |
|
|
|
18.8 |
|
|
|
0.5 |
|
|
|
41.1 |
|
Government |
|
|
20.9 |
|
|
|
18.3 |
|
|
|
49.5 |
|
|
|
63.5 |
|
Global Services |
|
|
26.5 |
|
|
|
26.7 |
|
|
|
81.3 |
|
|
|
70.1 |
|
Power |
|
|
5.9 |
|
|
|
(10.1 |
) |
|
|
12.0 |
|
|
|
16.8 |
|
| |
|
|
|
|
Total Operating Profit |
|
$ |
180.9 |
|
|
$ |
104.7 |
|
|
$ |
331.3 |
|
|
$ |
303.2 |
|
| |
|
|
|
|
| |
|
A reconciliation of the segment information to consolidated amounts for the three and nine
months ended September 30, 2005 and 2004 is as follows: |
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
|
Nine Months Ended |
|
| |
|
September 30 |
|
|
September 30 |
|
| $ in millions |
|
2005 |
|
|
2004 * |
|
|
2005 |
|
|
2004 * |
|
| |
Total segment operating
Profit |
|
$ |
180.9 |
|
|
$ |
104.7 |
|
|
$ |
331.3 |
|
|
$ |
303.2 |
|
Corporate
administrative and
general expense |
|
|
25.1 |
|
|
|
32.9 |
|
|
|
90.9 |
|
|
|
93.7 |
|
Interest income, net |
|
|
(1.7 |
) |
|
|
(1.1 |
) |
|
|
(3.2 |
) |
|
|
(1.0 |
) |
| |
|
|
|
|
Earnings before taxes |
|
$ |
157.5 |
|
|
$ |
72.9 |
|
|
$ |
243.6 |
|
|
$ |
210.5 |
|
| |
|
|
|
|
|
|
|
| * |
|
Cost of revenues as previously reported in the Form 10-Q for the quarterly period
ended September 30, 2004 has been reduced by $9.2 million to reclassify certain accrual
adjustments that were previously reported as corporate administrative and general expense.
This reclassification increased previously reported segment operating profit in the
following amounts: Oil & Gas, $4.4 million; Industrial & Infrastructure, $3.5 million; and
Global Services, $1.3 million. |
10
FLUOR CORPORATION
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS
(CONTINUED)
UNAUDITED
| |
|
The following table summarizes non-operating (income) and expense items reported in
corporate administrative and general expense: |
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
|
Nine Months Ended |
|
| |
|
September 30 |
|
|
September 30 |
|
| $ in millions |
|
2005 |
|
|
2004 |
|
|
2005 |
|
|
2004 |
|
| |
Sales of portfolio properties |
|
$ |
(10.4 |
) |
|
$ |
(5.4 |
) |
|
$ |
(14.6 |
) |
|
$ |
(12.8 |
) |
Other, net |
|
|
0.4 |
|
|
|
0.1 |
|
|
|
2.8 |
|
|
|
1.6 |
|
| |
|
|
|
|
Total |
|
$ |
(10.0 |
) |
|
$ |
(5.3 |
) |
|
$ |
(11.8 |
) |
|
$ |
(11.2 |
) |
| |
|
|
|
|
| |
|
Total assets for the Oil & Gas segment decreased to $521.8 million at September 30, 2005
from $731.2 million at December 31, 2004. The change was the primary result of the
settlement of claims on the Hamaca Crude Upgrader project (see further discussion in Note
9). Total assets for the companys other segments have generally fluctuated in response to
changes in the stages of project execution activities during the current year. |
| |
| (7) |
|
In December 2004, the company filed a shelf registration statement for the issuance of up
to $500 million of any combination of debt securities or common stock, the proceeds from which
could be used for debt retirement, the funding of working capital requirements or other
corporate purposes. The company has entered into a distribution agreement for up to 2,000,000
shares of common stock. During the quarter ended September 30, 2005, no shares were sold
under this distribution agreement. For the nine months ended September 30, 2005, the company
sold 758,367 shares realizing net proceeds of $41.8 million. |
| |
| (8) |
|
During the third quarter of 2005, the company implemented a plan design change to a non-U.S.
defined benefit plan, retroactive to January 1, 2005 and revised certain assumptions for the
plan. The impact of these changes was a reduction of $7.7 million to net periodic pension
expense for the current year, $5.8 million of which is included in the net periodic pension
expense for the three and nine months ended September 30, 2005. |
| |
| |
|
Net periodic pension expense for defined benefit pension plans includes the following
components: |
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
|
Nine Months Ended |
|
| |
|
September 30 |
|
|
September 30 |
|
| $ in thousands |
|
2005 |
|
|
2004 |
|
|
2005 |
|
|
2004 |
|
| |
Service cost |
|
$ |
5,466 |
|
|
$ |
8,828 |
|
|
$ |
23,633 |
|
|
$ |
26,525 |
|
Interest cost |
|
|
9,467 |
|
|
|
10,574 |
|
|
|
31,361 |
|
|
|
31,772 |
|
Expected return on assets |
|
|
(12,943 |
) |
|
|
(12,586 |
) |
|
|
(39,672 |
) |
|
|
(37,815 |
) |
Amortization of transition asset |
|
|
3 |
|
|
|
(177 |
) |
|
|
9 |
|
|
|
(531 |
) |
Amortization of prior service cost |
|
|
(27 |
) |
|
|
(25 |
) |
|
|
(82 |
) |
|
|
(77 |
) |
Recognized net actuarial loss |
|
|
3,019 |
|
|
|
4,621 |
|
|
|
11,773 |
|
|
|
13,869 |
|
| |
|
|
|
|
Net periodic pension expense |
|
$ |
4,985 |
|
|
$ |
11,235 |
|
|
$ |
27,022 |
|
|
$ |
33,743 |
|
| |
|
|
|
|
| |
|
The company currently expects to fund approximately $80 million to $100 million during 2005
compared with $30 million funded in 2004. During the nine months ended September 30, 2005,
contributions of approximately $39 million were made to the companys non-U.S. defined
benefit pension plans. |
11
FLUOR CORPORATION
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS
(CONTINUED)
UNAUDITED
Net periodic postretirement benefit cost includes the following components:
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
|
Nine Months Ended |
|
| |
|
September 30 |
|
|
September 30 |
|
| $ in thousands |
|
2005 |
|
|
2004 |
|
|
2005 |
|
|
2004 |
|
| |
Service cost |
|
$ |
|
|
|
$ |
|
|
|
$ |
|
|
|
$ |
|
|
Interest cost |
|
|
400 |
|
|
|
420 |
|
|
|
1,200 |
|
|
|
1,387 |
|
Expected return on assets |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Amortization of prior service cost |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
Recognized net actuarial loss |
|
|
225 |
|
|
|
142 |
|
|
|
675 |
|
|
|
604 |
|
| |
|
|
|
|
Net periodic postretirement
benefit cost |
|
$ |
625 |
|
|
$ |
562 |
|
|
$ |
1,875 |
|
|
$ |
1,991 |
|
| |
|
|
|
|
The preceding information does not include amounts related to benefit plans applicable to
employees associated with certain contracts with the U.S. Department of Energy because the
company is not responsible for the current or future funded status of these plans.
| (9) |
|
The company and certain of its subsidiaries are contingently liable for commitments and
performance guarantees arising in the ordinary course of business. Clients have made claims
arising from engineering and construction contracts against the company, and the company has
made claims against clients for costs incurred in excess of the current contract provisions.
The company recognizes certain significant claims for recovery of incurred costs when it is
probable that the claim will result in additional contract revenue and when the amount of the
claim can be reliably estimated. Recognized claims against clients amounted to $134 million
and $105 million at September 30, 2005 and December 31, 2004, respectively. The company does
not expect that failure to realize claim recoveries will have a material adverse effect on its
consolidated financial position or results of operations. |
| |
| |
|
The company participates in a 50/50 joint venture for a transportation infrastructure
project located in California. In 2004, the company recorded a $28 million charge for its
proportional share of estimated cost overruns on the project. The project continues to
experience circumstances, such as owner-directed scope changes and delays that could result
in additional charges in the future. The company continues to evaluate the impact of these
matters on its estimated project costs, as well as claims for recoveries and other
contingencies on the project. Based on this evaluation, the company recorded an additional
charge of $3.2 million during the third quarter of 2005. |
| |
| |
|
The company and certain of its subsidiaries are involved in litigation in the ordinary
course of business. As of September 30, 2005, several matters relating to completed and
in-progress projects and certain other matters are in the dispute resolution process. The
following discussion provides a background and current status of certain of these matters: |
| |
| |
|
Hamaca Crude Upgrader |
| |
| |
|
During the third quarter of 2005 the company settled all outstanding claims with the owners
consortium on the Hamaca Crude Upgrader Project in Jose, Venezuela. The pending arbitration
proceedings have been dismissed. The settlement is intended to reimburse the company for
its incurred costs arising from disputed change orders on the project and for its cost of
capital in funding those incurred costs. As a result, in the third quarter, all project
related costs previously deferred were eliminated from the balance sheet and the settlement
was recognized in revenue resulting in recognition of $30.5 million in pre-tax earnings in
the Oil & Gas segment. |
12
FLUOR CORPORATION
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS
(CONTINUED)
UNAUDITED
Ritz Carlton Cayman Islands
On June 23, 2005, Fluor Daniel Caribbean, Inc. (FD Caribbean), a wholly owned subsidiary
of the company, received an unfavorable jury verdict awarding $28.8 million to the developer
of a resort hotel project in the Caribbean. FD Caribbean was the general contractor on the
project, which is located in the Cayman Islands. As a consequence, the company recorded a
$65 million charge in its second quarter to recognize the jury award, estimated attorney
fees and pre-judgment interest, and reversal of previously billed accounts receivable for
work performed on the project. At the time of the original jury decision, the company
strongly believed the verdict was not supported by the facts or by applicable law. On
September 15, 2005, the judge who tried the case granted the companys motion for a new
trial, setting aside the unfavorable verdict in its totality. On September 29, 2005, in
lieu of a new trial, the parties have stipulated to a judgment of no liability in favor of
either side, and the action has been dismissed with prejudice.
The financial impact in the third quarter of 2005 is a reversal of the jury award including
estimated interest and attorney fees totaling $32.9 million. The reversal restores the
companys ability to absorb foreign taxes incurred in high tax jurisdictions, resulting in
the recognition of foreign tax credits that could not previously be utilized.
London Connect Project
The company filed for arbitration proceedings in February 2005 in connection with its London
Connect Project, a $500 million lump sum project to design and install a telecommunications
network that allows reception and transmissions throughout the London Underground system.
The company is seeking relief through arbitration proceedings for two issues. The first is
the overall delay and disruption related to the contract, which has hearings scheduled to
commence in May 2006. The second is for scope disputes concerning the enabling of the
various train stock to accept the new telecommunications network equipment. The company has
not received a procedural order indicating when hearings will begin on the second issue.
Costs incurred amounting to $22.7 million relating to delay and disruption are being
recognized as claims.
Embassy Projects
The company has 11 embassy projects that are in various stages of completion under contracts
with the United States Department of State. The company has recognized losses totaling
$41.8 million in the nine months ended September 30, 2005 due to unanticipated circumstances
on four of these projects. Claims for equitable adjustment totaling approximately $84
million have been identified on seven projects and costs totaling
$43.3 million related to these claims have been
incurred and recognized in revenue in the nine months ended September 30, 2005. Additional
claim recoveries continue to be evaluated. These projects have been adversely impacted by
higher costs due to scope changes, unexpected execution problems, increases in material cost
and subcontractor difficulties. The company is seeking recoveries and is preparing requests
for equitable adjustment which will be submitted to the client in the fourth quarter of
2005.
U.S. Department of Justice Civil Lawsuit
U.S.D.C., Central District of California
On November 1, 2005, the company entered into an agreement to settle a civil lawsuit without
any admission of company liability involving the U.S. Department of Justice. The case,
initiated in March 2000 by a former employee, was settled for $12.5 million, resolving a
dispute relating to the companys distribution of overhead expenses to government contracts
between 1995 and 1998. The case had been under court-ordered seal. A pre-tax charge of $5
million is included in the
13
FLUOR CORPORATION
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS
(CONTINUED)
UNAUDITED
operating results of the Government segment for the third quarter
of 2005. The remaining $7.5 million had been previously provided, and therefore, did not
affect operating results for the third quarter of 2005.
The settlement relates to operations in the late 1990s and does not impact current
operations. The companys government accounting practices are well documented and have been
continuously reviewed and accepted by government regulators and third-party experts and the
company believes that it would have ultimately prevailed. However, the settlement allows
the company to focus on current and future operations without further distraction.
Securities Class Action Litigation
U.S.D.C., Central District, Southern Division, California
Without any admission of company liability, the company has consummated settlement of an
action in which the plaintiffs alleged that certain Fluor officers and directors violated
the Securities Exchange Act of 1934 by providing false or misleading statements about the
companys business and prospects. These complaints purported to be class action complaints
brought on behalf of purchasers of the companys stock during the period from May 22, 1996
through February 18, 1997. During the first quarter of 2005 the company, its insurer and the
plaintiffs reached an agreement to settle this proceeding for $18 million without any
admission of company liability, of which $16 million was paid by the companys insurers.
The remaining $2 million had been previously provided, and therefore, did not affect
operating results for the first half of 2005. A hearing to confirm the settlement was held
on June 27, 2005 and the court approved the settlement on June 29, 2005.
Fluor Daniel International and Fluor Arabia Ltd. v. General Electric Company, et al
In October 1998, Fluor Daniel International and Fluor Arabia Ltd. filed a complaint in the
United States District Court for the Southern District of New York against General Electric
Company and certain operating subsidiaries as well as Saudi American General Electric, a
Saudi Arabian corporation. The complaint seeks damages in connection with the procurement,
engineering and construction of the Rabigh Combined Cycle Power Plant in Saudi Arabia.
Subsequent to a motion to compel arbitration of the matter, the company initiated
arbitration proceedings in New York under the American Arbitration Association international
rules. The evidentiary phase of the arbitration has been concluded. In January 2005 the
arbitration panel indicated that it would be rendering its decision in two phases; the first
to be a decision on entitlement and second, a decision on damages. On May 4, 2005 the
arbitration panel issued a partial award on entitlement issues which confirmed Fluors
entitlement to recovery of certain of its claims for costs incurred in construction of the
plant. A decision determining the amount recoverable has yet to be issued by the
arbitration panel.
Dearborn Industrial Project
The Dearborn Industrial Project (the Project) started as a co-generation combined cycle
power plant project in Dearborn, Michigan. The initial Turnkey Agreement, dated November 24,
1998, consisted of three phases. Commencing shortly after Notice to Proceed, the
owner/operator, Dearborn Industrial Generation (DIG), issued substantial change orders
enlarging the scope of the project.
The Project was severely delayed with completion of Phase II. DIG unilaterally took over
completion and operation of Phase II and commissioned that portion of the plant. Shortly
thereafter, DIG drew upon a $30 million letter of credit which Duke/Fluor Daniel (D/FD)
expects to recover upon resolution of the dispute. D/FD retains lien rights (in fee)
against the project. In October 2001, D/FD commenced an action in Michigan State Court to
foreclose on the lien interest.
14
FLUOR CORPORATION
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS
(CONTINUED)
UNAUDITED
In December 2001, DIG filed a responsive pleading denying liability and simultaneously
served a demand for arbitration to D/FD claiming, among other things, that D/FD is liable to
DIG for alleged construction delays and defective engineering and construction work at the
Dearborn plant. The court has ordered the matter to arbitration. The lien action remains
stayed pending completion of the arbitration of D/FDs claims against DIG and DIGs claims
against D/FD. An arbitration panel has been appointed and the arbitration is underway.
| (10) |
|
In the ordinary course of business, the company enters into various agreements providing
financial or performance assurances to clients on behalf of certain unconsolidated
subsidiaries, joint ventures and other jointly executed contracts. These agreements are
entered into primarily to support the project execution commitments of these entities. The
guarantees have various expiration dates ranging from mechanical completion of the facilities
being constructed to a period extending beyond contract completion in certain circumstances.
The maximum potential payment amount of an outstanding performance guarantee is the remaining
cost of work to be performed by or on behalf of third parties under engineering and
construction contracts. Amounts that may be required to be paid in excess of estimated costs
to complete contracts in progress are not estimable. For cost reimbursable contracts amounts
that may become payable pursuant to guarantee provisions are normally recoverable from the
client for work performed under the contract. For lump sum or fixed price contracts, this
amount is the cost to complete the contracted work less amounts remaining to be billed to the
client under the contract. Remaining billable amounts could be greater or less than the cost
to complete. In those cases where costs exceed the remaining amounts payable under the
contract, the company may have recourse to third parties, such as owners, co-venturers,
subcontractors or vendors for claims. As of September 30, 2005, the amount of guarantees
outstanding measured on this basis increased to $2.4 billion compared with $1.8 billion as of
December 31, 2004 as the principal result of a new transportation infrastructure joint-venture
project. |
| |
| |
|
The company has a joint venture arrangement that will design, build, finance and maintain an
aircraft refueling facility at a United States Air Force base in Qatar for the Defense
Energy Support Center, an agency of the Department of Defense. The company has a 27.5
percent interest in the joint venture company. On April 29, 2005, the joint venture entered
into an agreement for project financing which includes a joint and several project
completion guarantee by the members of the joint venture. The maximum potential amount of
future payments that could be required under the guarantee is $76.5 million, the maximum
principal amount available under the financing arrangement, plus any accrued interest. |
| |
| |
|
During the third quarter of 2005 the company was awarded a $524 million Infrastructure
project to design, build, maintain and finance a new telecommunications system throughout
Englands motorways. The project will be executed through a joint venture in which the
company owns a 45 percent interest. The joint venture will borrow approximately $260
million on a non-recourse basis which along with partner capital contributions totaling approximately $40 million will be
used to construct the upgraded telecommunications infrastructure. During construction the
existing telecommunications system will be operated and maintained. Upon completion of the
upgrade the entire system will be operated and maintained under a services agreement
extending through 2016. The company is currently evaluating the joint
venture arrangement and will determine any additional reporting
responsibilities with respect to its participation in the fourth
quarter. |
| |
| |
|
The company maintains a variety of commercial commitments that are generally made available
to provide support for various commercial provisions in its engineering and construction
contracts. The company has $761 million in committed and uncommitted lines of credit to
support letters of credit. Letters of credit are provided to clients in the ordinary course
of business in lieu of retention
|
15
FLUOR CORPORATION
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS
(CONTINUED)
UNAUDITED
or for performance and completion guarantees on engineering
and construction contracts. As of September 30, 2005, the company had utilized $309 million
of its letter of credit capacity compared with $392 million as of December 31, 2004. The
company also posts surety bonds primarily on state and local government projects to
guarantee its performance on contracts.
Financial guarantees, made in the ordinary course of business on behalf of clients and
others in certain limited circumstances, are entered into with financial institutions and
other credit grantors and generally obligate the company to make payment in the event of a
default by the borrower. Most arrangements require the borrower to pledge collateral in the
form of property, plant and equipment which is deemed adequate to recover amounts the
company might be required to pay. As of September 30, 2005, no material changes to
financial guarantees of the debt of third parties had occurred since the filing of the
companys December 31, 2004 annual report on Form 10-K.
| (11) |
|
On May 10, 2005, the company announced its decision to relocate its corporate headquarters
from Southern California to the Dallas/Fort Worth metropolitan area. This move is expected to
improve operational efficiency and position the company to more effectively serve its global
client base. Of the approximately 390 headquarters staff presently located in Aliso Viejo,
California, approximately 200 employees will either stay in Southern California or move to
other U.S. office locations. Approximately 60 employees will relocate to the new Texas
headquarters where approximately 120 additional employees are expected to be hired.
Approximately 130 employees will leave the company as a result of the move. |
| |
| |
|
The cost of employee displacements are being accrued ratably starting in the third quarter
of 2005 through the anticipated date of the Southern California headquarters office closure
in the second quarter of 2006. All other relocation and hiring costs will be charged to
expense as incurred. |
| |
| |
|
For the three months ended September 30, 2005, corporate administrative and general expenses
include $2.5 million for relocation costs, which comprises the accrual for employee
displacement costs and other direct expenses. Employee relocation and hiring costs and
facility relocation costs totaling approximately $3 million are expected to be incurred
during the remainder of 2005, with an additional amount of approximately $19 million to be
incurred during 2006. All future employee displacement, relocation and hiring costs will
also be included in corporate administrative and general expense. |
| |
| |
|
The existing corporate facility in Aliso Viejo was sold in September 2005. A short-term,
market rate lease-back has been negotiated with the buyer that will allow the company to
continue to occupy the facility for up to 18 months. The capital cost of the new Texas
headquarters is expected to approximate $60 million and will be paid from available cash
resources including proceeds from the sale of the existing headquarters facility. |
16
Item 2. Managements Discussion and Analysis of Financial Condition
and Results of Operations
FLUOR CORPORATION
The following discussion and analysis is provided to increase understanding of, and should be read
in conjunction with, the Condensed Consolidated Financial Statements and accompanying notes and the
companys December 31, 2004 annual report on Form 10-K. For purposes of reviewing this document,
operating profit is calculated as revenues less cost of revenues.
CAUTIONARY STATEMENT REGARDING FORWARD-LOOKING STATEMENTS
Certain statements made herein, including statements regarding the companys projected revenues and
earnings levels, new awards and backlog levels and the implementation of strategic initiatives and
organizational changes are forward-looking in nature. These forward-looking statements reflect
current analysis of existing information and are subject to various risks and uncertainties. As a
result, caution must be exercised in relying on forward-looking statements. Due to known and
unknown risks, the companys actual results may differ materially from its expectations or
projections. Factors potentially contributing to such differences include, among others:
| |
|
Difficulties or delays incurred in the execution of construction contracts, including performance by our joint venture
partners, resulting in cost overruns or liabilities; |
| |
| |
|
A failure to obtain favorable results in existing or future litigation or dispute resolution proceedings; |
| |
| |
|
The potential impact of certain tax matters including, but not limited to, those from foreign operations and the
ongoing audits by tax authorities and those resulting from the companys reverse spin-off transaction consummated
November 30, 2000 involving Massey Energy Company; |
| |
| |
|
Changes in global business, economic (including currency risk), political and social conditions; |
| |
| |
|
The companys failure to receive anticipated new contract awards and the related impacts on staffing levels and costs; |
| |
| |
|
Customer cancellations of, or scope adjustments to, existing contracts, including our government contracts that may be
terminated at any time; |
| |
| |
|
The cyclical nature of many of the markets the company serves and its vulnerability to downturns; |
| |
| |
|
Failure to meet timely completion or performance standards could result in higher costs and reduced profits or, in some
cases losses on projects; |
| |
| |
|
Customer delays or defaults in making payments; |
| |
| |
|
Possible limitations of bonding capacity; |
| |
| |
|
Restrictions imposed by credit facilities; |
| |
| |
|
Limitations on cash transfers from subsidiaries may restrict the companys ability to satisfy financial obligations, or
to pay interest or principal when due on outstanding debt; |
| |
| |
|
Competition in the global engineering, procurement and construction industry; |
| |
| |
|
The companys ability to identify and successfully integrate acquisitions; |
| |
| |
|
The impact of past and future environmental, health and safety regulations; and |
| |
| |
|
Restrictions on possible transactions imposed by Delaware law. |
While most risks affect only future costs or revenues anticipated by the company, some risks may
relate to accruals that have already been reflected in results of operations. The companys
failure to receive payments of accrued amounts or if liabilities are incurred in excess of amounts
previously recognized, a charge against future earnings could result.
Additional information concerning these and other factors can be found in our press releases as
well as our periodic filings with the Securities and Exchange Commission, including the discussion
under the heading Item 1. Business-Company Risk Factors in the companys Form 10-K filed March 4,
2005. These filings are available publicly on the SECs website at http://www.sec.gov, on Fluors
website at http://investor.fluor.com or upon request from Fluors Investor Relations Department:
(949) 349-3909. The company disclaims any intent or obligation to update its forward-looking
statements, whether as a result of new information, future events or otherwise.
17
RESULTS OF OPERATIONS
Results of operations in the three and nine months ended September 30, 2005 were net earnings of
$131.2 million or $1.51 per diluted share and $162.2 million or $1.88 per diluted share,
respectively. These results compare with net earnings of $47.3 million or $0.57 per diluted share
and $138.8 million or $1.68 per diluted share, respectively for the corresponding periods of 2004.
The Oil & Gas, Government and Global Services segments had improved or essentially unchanged
performance in the three months ended September 30, 2005 compared with the same period in 2004.
Pre-tax operating results for the three month period in 2005 include $30.5 million from the
settlement of claims on the Hamaca Crude Oil Upgrader (Hamaca) project and $32.9 million from the
partial reversal of a second quarter provision for a jury award and other costs discussed further
below. In addition, gains of $10.4 million from the sale of the current corporate facility and
another real estate asset were recognized during the 2005 three month period. During the 2004 three
month period, a $5.5 million pre-tax gain related to the final disposal of a residual interest in a
property that was sold by the company in 1985 was realized. The pre-tax operating results for the
nine months ended September 30, 2005 and 2004 include gains of $14.6 million and $7.4 million,
respectively, from the sale of real estate assets. In addition, the 2004 nine month period
includes the $5.5 million gain from the residual property interest previously mentioned.
Revenues for the three and nine months ended September 30, 2005 were $3.4 billion and $9.2 billion,
respectively, compared with $2.4 billion and $6.6 billion, respectively for the 2004 comparison
periods. All segments have experienced significant revenue growth in 2005. Additionally, the Oil
& Gas segment recognized approximately $294 million of revenue during the third quarter of 2005 as
the result of the Hamaca settlement.
As the result of international embassy contract provisions recorded in the first quarter of 2005
and a $65 million charge during the second quarter of 2005 associated with the unfavorable jury
award on a project in the Cayman Islands, which represents a foreign loss, the companys ability to
absorb foreign taxes incurred in high tax jurisdictions was significantly diminished; accordingly,
certain foreign earnings were subject to both U.S. and foreign taxes without an offsetting foreign
tax credit during the first half of the year. The set-aside of the jury verdict and no-liability
resolution of the Cayman Islands hotel project, along with the settlement of the Hamaca Crude
Upgrader project claims during the third quarter of 2005, substantially reverse the foreign losses
recorded in prior quarters and restore the companys ability to absorb foreign taxes incurred in
high tax jurisdictions. This coupled with the tax benefit attributable to the foreign repatriation
provision enacted under the American Jobs Creation Act of 2004 (the Jobs Act) discussed further
below (see OTHER) gave rise to the low 16.7 percent effective tax rate in the current quarter and
restored the year-to-date rate to a more expected level of 33.4 percent.
Consolidated new awards for the three and nine months ended September 30, 2005 were $2.5 billion
and $9.1 billion, respectively, compared with $3.2 billion and $9.7 billion, respectively, in the
comparable 2004 periods. The Oil & Gas and Industrial & Infrastructure segments had lower new
awards in the 2005 three-month period, partly offset by an increase for the Global Services
segment.
Consolidated backlog at September 30, 2005 increased 7 percent to $14.7 billion from $13.7 billion
at September 30, 2004. Approximately 59 percent of consolidated new awards for the nine months
ended September 30, 2005 were for projects located outside of the United States. As of September
30, 2005, approximately 62 percent of consolidated backlog relates to international projects.
Although backlog reflects business which is considered to be firm, cancellations or scope
adjustments may occur. Backlog is adjusted to reflect any known project cancellations, deferrals
and revised project scope and cost, both upward and downward.
18
OIL & GAS
Revenues and operating profit for the Oil & Gas segment are summarized as follows:
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
|
Nine Months Ended |
|
| |
|
September 30 |
|
|
September 30 |
|
| $ in millions |
|
2005 |
|
|
2004 |
|
|
2005 |
|
|
2004 |
|
| |
Revenues |
|
$ |
1,447.5 |
|
|
$ |
1,000.4 |
|
|
$ |
3,844.4 |
|
|
$ |
2,360.7 |
|
Operating profit |
|
|
84.1 |
|
|
|
51.0 |
|
|
|
188.0 |
|
|
|
111.7 |
|
Commencing in the third quarter of 2004, as the result of a shift in the markets served by and the
types of projects awarded to ICA Fluor Daniel (ICA Fluor), its operating results, new awards and
backlog are included in the Oil & Gas segment. ICA Fluor was previously included in the Power
segment. Prior periods have not been restated for the change in segment classification of ICA
Fluor.
In the first quarter of 2005, the chemicals business line, which had previously been part of the
Industrial & Infrastructure segment, was realigned under the Oil & Gas segment. This change was
made to better match the needs for the large number of petrochemical projects anticipated over the
next few years with the Oil & Gas segments project support infrastructure. All prior periods have
been restated to reflect this change.
Revenues increased by 45 percent and 63 percent in the three and nine months ended September 30,
2005 compared with the corresponding periods of 2004 due to the continued increase in global
project execution activities that have been experienced over the past two years and recognized
revenues of $294 million on the Hamaca project settlement, which is discussed further below.
Operating profit for the three months ended September 30, 2005 includes $30.5 million from the
settlement of claims on the Hamaca project. Operating profit margin has increased to 5.8 percent
and 4.9 percent for the three and nine month periods ended September 30, 2005 compared with 5.1
percent and 4.7 percent for the corresponding periods of 2004. Excluding the impact of the Hamaca
settlement, the operating profit margins have declined slightly during 2005, primarily as the
result of client furnished materials expended during the current phase of construction activity.
During the third quarter of 2005 the company settled all outstanding claims with the owners
consortium on the Hamaca Crude Upgrader Project in Jose, Venezuela. The pending arbitration
proceedings have been dismissed. The settlement is intended to reimburse the company for its
incurred costs arising from disputed change orders on the project and for its cost of capital in
funding those incurred costs. As a result, in the third quarter, all project related costs
previously deferred were eliminated from the balance sheet and the settlement was recognized in
revenue resulting in recognition of $30.5 million in pre-tax earnings in the Oil & Gas segment.
Total assets for the Oil & Gas segment decreased to $521.8 million at September 30, 2005 from
$731.2 million at December 31, 2004 primarily as a result of the settlement of claims on the Hamaca
project.
New awards for the three months ended September 30, 2005 were $179 million compared with $906
million in the comparable period of 2004. The decline in new awards during the 2005 period
resulted primarily from a delay in the award of one large gas complex project that was received and
will be recognized in the fourth quarter.
Backlog at September 30, 2005 decreased to $5.3 billion compared with $5.5 billion at September 30,
2004, reflecting the decline in third quarter new awards. A backlog adjustment for the Hamaca
settlement was recorded during the third quarter of 2005, concurrent with the revenue recognition,
resulting in no net change in backlog during the current quarter.
19
INDUSTRIAL & INFRASTRUCTURE
Revenues and operating profit for the Industrial & Infrastructure segment are summarized as
follows:
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
|
Nine Months Ended |
|
| |
|
September 30 |
|
|
September 30 |
|
| $ in millions |
|
2005 |
|
|
2004 |
|
|
2005 |
|
|
2004 |
|
| |
Revenues |
|
$ |
857.3 |
|
|
$ |
521.4 |
|
|
$ |
2,085.5 |
|
|
$ |
1,432.6 |
|
Operating profit |
|
|
43.5 |
|
|
|
18.8 |
|
|
|
0.5 |
|
|
|
41.1 |
|
In the first quarter of 2005, the chemicals business line, which had previously been part of the
Industrial & Infrastructure segment, was realigned under the Oil & Gas segment. This change was
made to better match the needs for the large number of petrochemical projects anticipated over the
next few years with the Oil & Gas segments project support infrastructure. All prior periods have
been restated to reflect this change.
Revenues have increased significantly during 2005 as the result of the strength of 2004 contract
awards, including substantial amounts of customer-furnished materials.
Operating profit for the three months ended September 30, 2005 increased significantly compared
with the three months ended September 30, 2004. The increase includes $32.9 million from the
partial reversal of a second quarter provision for a jury award and other costs on a Cayman Islands
project, partly offset by lower current year operating profit contribution from an international
infrastructure project and a charge of $3.2 million associated with a transportation infrastructure
project in California.
Operating profit for the nine months ended September 30, 2005 decreased significantly compared with
the same period in 2004. This decrease resulted primarily from the $32.1 million charge relating
to the no-liability resolution of a Cayman Islands project, the $3.2 million transportation
infrastructure project charge discussed in the previous paragraph, a $9 million second quarter
charge for disputed change orders on another project and first quarter of 2005 claim settlements
totaling approximately $10 million.
On June 23, 2005, Fluor Daniel Caribbean, Inc. (FD Caribbean), a wholly owned subsidiary of the
company, received an unfavorable jury verdict awarding $28.8 million to the developer of a resort
hotel project in the Caribbean. FD Caribbean was the general contractor on the project, which is
located in the Cayman Islands. As a consequence, the company recorded a $65 million charge in its
second quarter to recognize the jury award, estimated attorney fees and pre-judgment interest, and
reversal of previously billed accounts receivable for work performed on the project. At the time of
the original jury decision, the company strongly believed the verdict was not supported by the
facts or by applicable law. On September 15, 2005, the judge who tried the case granted the
companys motion for a new trial, setting aside the unfavorable verdict in its totality. On
September 29, 2005, in lieu of a new trial, the parties have stipulated to a judgment of no
liability in favor of either side, and the action has been dismissed with prejudice.
The financial impact in the third quarter of 2005 is a reversal of the jury award including
estimated interest and attorney fees totaling $32.9 million. The reversal also contributed to
restoring the companys ability to absorb foreign taxes incurred in high tax jurisdictions,
resulting in the recognition of foreign tax credits that could not previously be utilized.
The company participates in a 50/50 joint venture for a transportation infrastructure project
located in California. In 2004, the company recorded a $28 million charge for its proportional
share of estimated cost overruns on the project. The project continues to be subject to
circumstances, such as owner-directed scope changes and delays that could result in additional
charges in the future. The company continues to evaluate the impact of these circumstances on its
estimated project costs, as well as claims for recoveries
and other contingencies on the project. Based on this evaluation, the company recorded an
additional charge of $3.2 million during the third quarter of 2005.
20
The company filed for arbitration proceedings in February 2005 in connection with its London
Connect Project, a $500 million lump sum project to design and install a telecommunications network
that allows reception and transmissions throughout the London Underground system. The company is
seeking relief through arbitration proceedings for two issues. The first is the overall delay and
disruption related to the contract, which has hearings scheduled to commence in May 2006. The
second is for scope disputes concerning the enabling of the various train stock to accept the new
telecommunications network equipment. The company has not received a procedural order indicating
when hearings will begin on the second issue. Costs incurred amounting to $22.7 million relating
to delay and disruption are being recognized as claims.
New awards for the three months ended September 30, 2005 were $690 million compared with $840
million for the 2004 comparison period. Backlog decreased to $4.0 billion at September 30, 2005
compared with $4.6 billion at September 30, 2004. During the first three quarters of 2005, the
segment experienced three life sciences project cancellations of $282 million, $80 million and $334
million, respectively.
GOVERNMENT
Revenues and operating profit for the Government segment are summarized as follows:
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
|
Nine Months Ended |
|
| |
|
September 30 |
|
|
September 30 |
|
| $ in millions |
|
2005 |
|
|
2004 |
|
|
2005 |
|
|
2004 |
|
| |
Revenues |
|
$ |
651.3 |
|
|
$ |
529.7 |
|
|
$ |
1,859.6 |
|
|
$ |
1,698.7 |
|
Operating profit |
|
|
20.9 |
|
|
|
18.3 |
|
|
|
49.5 |
|
|
|
63.5 |
|
The increase in revenues in the three and nine months ended September 30, 2005 compared with the
same periods in the prior year was primarily the result of increases in the level of work performed
on projects in Iraq. Work performed in Iraq contributed approximately $232 million and $575
million, respectively, in revenue in the three and nine months ended September 30, 2005 compared
with $145 million and $503 million, respectively, in the comparable 2004 periods.
The increase in operating profit for the three months ended September 30, 2005 compared with the
corresponding period in 2004 includes the favorable impacts of increased work in Iraq and improved
margin on Department of Energy projects, partly offset by a $5 million charge related to the
settlement of a civil lawsuit with the U.S. Department of Justice and additional provisions of $4.3
million on certain embassy projects.
Operating profit for the nine months ended September 30, 2005 includes the impact of provisions
recognized on four embassy projects totaling $41.8 million. The company has 11 embassy projects
that are in various stages of completion under contracts with the United States Department of
State. Claims for equitable adjustment on seven of these projects totaling approximately $84.0
million have been identified, and $43.3 million in costs relating to these claims have been
incurred and recognized in revenue in the nine months ended September 30, 2005. Additional claim
recoveries continue to be evaluated. These embassy projects have been adversely impacted by higher
costs due to scope changes, unexpected execution problems, increases in material cost and
subcontractor difficulties. The impact of the embassy provisions was partly offset by increased
margin on the Fernald project. The segment has recognized unbilled fees totaling $124 million
related to this project at September 30, 2005, including $6 million and $33 million, respectively,
during the three and nine months ended September 30, 2005, compared with $10 million and $17
million, respectively, in the same periods of 2004. Fees recognized in 2005 include the favorable
impact of accelerated completion. These fees will be billed upon project completion in 2006.
New awards for the three months ended September 30, 2005 was $1.1 billion, slightly below the $1.2
billion of new awards in the 2004 comparison period.
21
Backlog at September 30, 2005 was $1.7 billion, level with backlog at the end of the third quarter
of 2004.
GLOBAL SERVICES
Revenues and operating profit for the Global Services segment are summarized as follows:
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
Nine Months Ended |
| |
|
September 30 |
|
September 30 |
| $ in millions |
|
2005 |
|
2004 |
|
2005 |
|
2004 |
| |
Revenues |
|
$ |
367.8 |
|
|
$ |
279.5 |
|
|
$ |
1,116.0 |
|
|
$ |
896.9 |
|
Operating profit |
|
|
26.5 |
|
|
|
26.7 |
|
|
|
81.3 |
|
|
|
70.1 |
|
Revenue increased 32 percent and 24 percent, respectively, in the three and nine months ended
September 30, 2005 compared with the same periods in 2004. The third quarter increase included
growth in all sectors of the business. The operating profit margin decreased to 7.2 percent in the
third quarter of 2005 compared with 9.6 percent in the 2004 period, principally as the result of a
shift in the mix of business during 2005 among the segments various service lines. The operating
profit margin for the nine months ended September 30, 2005 was consistent with the prior year
period.
New awards and backlog for Global Services reflect operations and maintenance activities only. The
equipment, temporary staffing and global procurement operations do not report backlog due to the
short turnaround between the receipt of new awards and the recognition of revenue. New awards for
the three months ended September 30, 2005 were $511 million compared with $275 million for the 2004
comparison period, reflecting the addition of a major environmental capital project for an existing
client and one new maintenance client. Also during the third quarter of 2005, a change of
circumstances occurred on a large maintenance contract which necessitated the removal of $400
million in client furnished materials from backlog. Backlog for Global Services at September 30,
2005 was $2.8 billion compared with $1.9 billion at September 30, 2004, reflecting the impact of
continued growth in the number of client sites served.
POWER
Revenues and operating profit (loss) for the Power segment are summarized as follows:
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
Nine Months Ended |
| |
|
September 30 |
|
September 30 |
| $ in millions |
|
2005 |
|
2004 |
|
2005 |
|
2004 |
| |
Revenues |
|
$ |
94.6 |
|
|
$ |
31.7 |
|
|
$ |
292.7 |
|
|
$ |
251.5 |
|
Operating profit (loss) |
|
|
5.9 |
|
|
|
(10.1 |
) |
|
|
12.0 |
|
|
|
16.8 |
|
As the result of a shift in the markets served by and the types of projects awarded to ICA Fluor,
commencing in the third quarter of 2004, its operating results, new awards and backlog are included
in the Oil & Gas segment rather than the Power segment where it was previously reported. Prior
periods have not been restated for the change in segment classification of ICA Fluor.
In July 2003, the company jointly announced with Duke Energy Corporation the decision to dissolve
the Duke/Fluor Daniel partnership (D/FD) as a result of the significant decline in the
construction of new power plants. The dissolution is not expected to have a material impact on
results of operations or financial position of the company. The dissolution is in progress and is
expected to be substantially completed in 2005 as remaining project activities are concluded.
22
Revenues increased significantly in the three months ended September 30, 2005 compared with the
same period in 2004. The improvement is the result of increasing project execution activity on
recent contract awards.
The 6.2 percent operating profit margin for the third quarter of 2005 includes the favorable impact
of closeouts of certain D/FD contracts. Unexpected costs associated with the start-up and
commissioning of a waste-coal power plant were the cause of the operating loss for the three months
ended September 30, 2004.
The operating profit margin declined to 4.1 percent for the nine months ended September 30, 2005
compared with 6.7 percent in the 2004 period. The 2004 margin reflects performance on projects
that were either completed or nearing completion where profit recognition is strongest, partly
offset by unexpected costs associated with the waste-coal power plant start-up and commissioning.
Operating profit in the 2004 nine-month period also includes the favorable impact of a settlement
for a dispute relating to a project that was completed in 2002.
Demand for new power generation has increased modestly in recent quarters following a downturn in
power plant construction activity. New project awards in the third quarter of 2005 were $13
million compared with $9 million in the prior year comparison period. Backlog at September 30,
2005 was $869 million compared with $78 million at September 30, 2004. All projects in backlog
will be performed 100 percent by Fluor.
OTHER
Corporate general and administrative expense for the three and nine months ended September 30, 2005
was $25.1 million and $90.9 million, respectively, compared with $32.9 million and $93.7 million in
the corresponding periods of 2004. Gains on the sale of real estate assets are included in both
years. Included in the three and nine months ended September 30, 2005 are pre-tax gains of $10.4
million and $14.6 million, respectively, from the sale of real estate assets. This compares with a
$7.4 million pre-tax gain from the sale of three real estate assets in the first quarter of 2004
and a $5.5 million pre-tax gain from the final disposal of a residual property interest in the
third quarter of 2004.
During the third quarter of 2005, net interest income was $1.7 million compared with $1.1 million
net interest income reported in the same period of 2004. For the nine months ended September 30,
2005 net interest income was $3.2 million compared to $1.0 million net interest income in the
corresponding period of 2004.
On May 10, 2005, the company announced its decision to relocate its corporate headquarters from
Southern California to the Dallas/Fort Worth metropolitan area. This move is expected to improve
operational efficiency and position the company to more effectively serve its global client base.
Of the approximately 390 headquarters staff presently located in Aliso Viejo, California,
approximately 200 employees will either stay in Southern California or move to other U.S. office
locations. Approximately 60 employees will relocate to the new Texas headquarters where
approximately 120 additional employees are expected to be hired. Approximately 130 employees will
leave the company as a result of the move.
The cost of employee displacements are being accrued ratably starting in the third quarter of 2005
through the anticipated date of the Southern California headquarters office closure in the second
quarter of 2006. All other relocation and hiring costs will be charged to expense as incurred.
For the three months ended September 30, 2005, corporate administrative expenses include $2.5
million for relocation costs, which comprises the accrual of employee displacement costs and other
direct expenses. Employee relocation and hiring costs and facility relocation costs totaling
approximately $3 million are expected to be incurred during the remainder of 2005, with an
additional amount of approximately $19 million to be incurred during 2006. All future employee
displacement, relocation and hiring costs will also be included in corporate administrative and
general expense.
23
The existing corporate facility in Aliso Viejo was sold in September 2005. A short-term, market
rate lease-back has been negotiated with the buyer that will allow the company to continue to
occupy the facility for up to 18 months. The cost of the new Texas headquarters is expected to
approximate $60 million and will be paid from available cash resources including proceeds from the
sale of the current headquarters facility.
The effective tax rate on the companys operations for the three and nine months ended September
30, 2005 was 16.7 percent and 33.4 percent compared with 35.2 percent and 34.1 percent in the 2004
comparison periods. The effective tax rate for the nine months ended September 30, 2005 has
returned to a more typical annualized level of 33.4 percent from the effective tax rate of 64.1
percent for the six months ended June 30, 2005. Foreign losses, including the international
embassy contract provisions discussed under Government above and the Cayman Islands project jury
award, reduced the companys ability to absorb excess foreign taxes incurred in high tax
jurisdictions, resulting in the significant increase of the effective tax rate during the first
half of 2005. The partial reversal of the Cayman Islands project jury award and the settlement of
the Hamaca project claims during the third quarter of 2005 substantially reversed the foreign
losses recorded in prior quarters and restored the companys ability to absorb foreign taxes
incurred in high tax jurisdictions. This coupled with the tax benefit attributable to the foreign
repatriation provision enacted under the American Jobs Creation Act of 2004 (the Jobs Act) as
more fully discussed below produced a favorable impact for the quarter. Nine month effective tax
rates for 2005 and 2004 are fairly comparable. The effective tax rate for the full current year is
projected to be between 28 and 33 percent compared with 33.6 percent for 2004.
On October 22, 2004, the Jobs Act was signed into law. Among its various provisions, the Jobs Act
creates a one-time incentive for U.S. corporations to repatriate certain qualified foreign earnings
by providing an 85 percent dividends received deduction, subject to specific reinvestment
guidelines and certain limitations. On December 21, 2004, the Financial Accounting Standards Board
(FASB) issued FASB Staff Position 109-2, Accounting and Disclosure Guidance for the Foreign
Earnings Repatriation Provision within the American Jobs Creation Act of 2004 (FSP 109-2). FSP
109-2 allows companies additional time beyond the financial reporting period in which the Jobs Act
was enacted to evaluate the effect of the Jobs Act on a companys plan for reinvestment or
repatriation of unremitted foreign earnings for the purpose of applying Statement of Financial
Accounting Standards (SFAS) No. 109, Accounting for Income Taxes.
On August 11, 2005, the companys Domestic Reinvestment Plan (the Plan) prepared pursuant to the
Jobs Act was approved by the companys Chief Executive Officer. The Plan was ratified by the
Executive Committee of the companys Board of Directors on August 29, 2005.
On September 29, 2005, approximately $89 million was repatriated from certain foreign subsidiaries
of the company, including certain previously taxed income and the base year amount as provided
under the repatriation provision of the Jobs Act. The results of operations for the three and nine
months ended September 30, 2005 include a tax benefit of $4.1 million attributable to the dividends
received deduction net of the foreign tax credits given up in exchange for such deduction. As the
computation of the above tax benefit took into account, among other things, the projected earnings
and foreign taxes to be incurred by the distributing subsidiaries for the full year of 2005, a
true-up will be required at the end of the year.
In addition, the computation of the above tax benefit was based on the repatriation statute enacted
under the Jobs Act and a series of notices issued to date by the U.S. Treasury Department and the
Internal Revenue Service (IRS) in connection with such repatriation provision. This tax benefit
may be impacted by future law changes enacted by Congress or the further guidance issued by the
U.S. Treasury Department or the IRS. The impact of such future changes will be reflected in the
financial reporting period in which any such change in law is enacted or becomes effective.
24
ACCOUNTING PRONOUNCEMENTS
In December 2004, the FASB issued SFAS No. 123 (revised 2004), Share-Based Payment (SFAS 123-R),
which is a revision of SFAS 123, Accounting for Stock-Based Compensation. SFAS 123-R supersedes
Accounting Principles Board (APB) Opinion No. 25, Accounting for Stock Issued to Employees (APB
25), and amends SFAS 95, Statement of Cash Flows. Generally, the approach in SFAS 123-R is
similar to the approach described in SFAS 123. However, SFAS 123-R requires all share-based
payments to employees, including grants of employee stock options, to be recognized in the income
statement based on their fair values. Upon adoption of SFAS 123-R, pro forma disclosure of the
impact of share-based payments to employees is no longer permitted.
The provisions of SFAS 123-R apply to awards granted after the required effective date of the
statement, which is no later than January 1, 2006 for the company. Initial application to existing
unvested stock option awards may be based on either a modified prospective method or a modified
retrospective method. The method of application selected by the company will determine which, if
any, previously reported operating results will be restated.
As permitted by SFAS 123, the company currently accounts for share-based payments to employees
using the intrinsic value method pursuant to APB 25 and, as such, recognizes no compensation cost
for employee stock options. Accordingly, the adoption of SFAS 123-Rs fair value method will have
an impact on results of operations, although it will have no impact on overall financial position.
The impact of adoption of SFAS 123-R will not be material based on unvested options outstanding at
September 30, 2005. Had SFAS 123-R been adopted in prior periods, the impact would be as presented
in the disclosure of pro forma earnings and earnings per share in Note 5 in the Condensed
Consolidated Financial Statements. Adoption of the new standard will also have an impact on the
timing of expense recognition for new stock based awards, as discussed in Note 5 in the Condensed
Consolidated Financial Statements.
SFAS 123-R also requires the benefits of tax deductions in excess of recognized compensation cost
to be reported as a financing cash flow, rather than as an operating cash flow as currently
required. This requirement will generally impact cash provided or utilized by operating activities
with equal offset in cash flows from financing activities in periods after adoption. While the
company cannot estimate what those amounts will be in the future (because they depend on, among
other things, when employees exercise stock options), the amounts of operating cash flows
recognized for such excess tax deductions were $11.0 million and $5.7 million in the nine month
periods ended September 30, 2005 and 2004, respectively.
LITIGATION AND MATTERS IN DISPUTE RESOLUTION
As of September 30, 2005, several matters relating to completed and in progress projects and
certain other matters are in the dispute resolution process. The following discussion provides a
background and current status of certain of these matters:
Hamaca Crude Upgrader
Discussion of the status of the Hamaca project is included above under Oil & Gas.
Ritz Carlton Cayman Islands
Discussion of the status of this project is included above under Industrial & Infrastructure.
London Connect Project
Discussion of the status of the London Connect project is included above under Industrial &
Infrastructure.
25
Embassy Projects
Discussion of the status of these projects is included above under Government.
U.S. Department of Justice Civil Lawsuit
U.S.D.C., Central District of California
On November 1, 2005, the company entered into an agreement to settle a civil lawsuit without any
admission of company liability involving the U.S. Department of Justice. The case, initiated in
March 2000 by a former employee, was settled for $12.5 million, resolving a dispute relating to the
companys distribution of overhead expenses to government contracts between 1995 and 1998. The
case had been under court-ordered seal. A pre-tax charge of $5 million is included in the
operating results of the Government segment for the third quarter of 2005. The remaining $7.5
million had been previously provided, and therefore, did not affect operating results for the third
quarter of 2005.
The settlement relates to operations in the late 1990s and does not impact current operations. The
companys government accounting practices are well documented and have been continuously reviewed
and accepted by government regulators and third-party experts and the company believes that it
would have ultimately prevailed. However, the settlement allows the company to focus on current
and future operations without further distraction.
Securities Class Action Litigation
U.S.D.C., Central District, Southern Division, California
Without any admission of company liability, the company has consummated settlement of an action in
which the plaintiffs alleged that certain Fluor officers and directors violated the Securities
Exchange Act of 1934 by providing false or misleading statements about the companys business and
prospects. These complaints purported to be class action complaints brought on behalf of purchasers
of the companys stock during the period from May 22, 1996 through February 18, 1997. During the
first quarter of 2005 the company, its insurer and the plaintiffs reached an agreement to settle
this proceeding for $18 million without any admission of company liability, of which $16 million
was paid by the companys insurers. The remaining $2 million had been previously provided, and
therefore, did not affect operating results for the first quarter of 2005. A hearing to confirm the
settlement was held on June 27, 2005 and the court approved the settlement on June 29, 2005.
Fluor Daniel International and Fluor Arabia Ltd. v. General Electric Company, et al
In October 1998, Fluor Daniel International and Fluor Arabia Ltd. filed a complaint in the United
States District Court for the Southern District of New York against General Electric Company and
certain operating subsidiaries as well as Saudi American General Electric, a Saudi Arabian
corporation. The complaint seeks damages in connection with the procurement, engineering and
construction of the Rabigh Combined Cycle Power Plant in Saudi Arabia. Subsequent to a motion to
compel arbitration of the matter, the company initiated arbitration proceedings in New York under
the American Arbitration Association international rules. The evidentiary phase of the arbitration
has been concluded. In January 2005 the arbitration panel indicated that it would be rendering its
decision in two phases; the first to be a decision on entitlement and second, a decision on
damages. On May 4, 2005 the arbitration panel issued a partial award on entitlement issues which
confirmed Fluors entitlement to recovery of certain of its claims for costs incurred in
construction of the plant. A decision determining the amount recoverable has yet to be issued by
the arbitration panel.
Dearborn Industrial Project
The Dearborn Industrial Project (the Project) started as a co-generation combined cycle power
plant project in Dearborn, Michigan. The initial Turnkey Agreement, dated November 24, 1998,
consisted of three phases. Commencing shortly after Notice to Proceed, the owner/operator, Dearborn
Industrial Generation (DIG), issued substantial change orders enlarging the scope of the project.
26
The Project was severely delayed with completion of Phase II. DIG unilaterally took over completion
and operation of Phase II and commissioned that portion of the plant. Shortly thereafter, DIG drew
upon a $30 million letter of credit which Duke/Fluor Daniel (D/FD) expects to recover upon
resolution of the dispute. D/FD retains lien rights (in fee) against the project. In October 2001,
D/FD commenced an action in Michigan State Court to foreclose on the lien interest.
In December 2001, DIG filed a responsive pleading denying liability and simultaneously served a
demand for arbitration to D/FD claiming, among other things, that D/FD is liable to DIG for alleged
construction delays and defective engineering and construction work at the Dearborn plant. The
court has ordered the matter to arbitration. The lien action remains stayed pending completion of
the arbitration of D/FDs claims against DIG and DIGs claims against D/FD. An arbitration panel
has been appointed and the arbitration is underway.
FINANCIAL POSITION AND LIQUIDITY
During the nine months ended September 30, 2005, cash was generated primarily from operations,
including cash received from the settlement of the Hamaca claims, the issuance of common stock and
the sale of certain real estate assets.
In the nine months ended September 30, 2005, cash provided by operating activities was $659.5
million and included cash received from the settlement of claims on the Hamaca project, earnings
sources and increases in advance billings on contracts in the Oil & Gas, Industrial &
Infrastructure and Government segments. Cash provided by operating activities during the first
nine months of 2004 was $17.3 million, which included reductions associated with progress on the
Hamaca project of $73.6 million and a $27.8 million decrease in advances from D/FD as power
projects were completed and advance payments previously received from clients on those projects
were expended.
Cash utilized by investing activities was $98.8 million in the first nine months of 2005 compared
with $25.7 million in the 2004 comparison period. During 2005 the company received $45.0 million
in proceeds from the sale of three real estate properties and $17.0 million from the disposal of
other property and equipment. Investing cash flows in the nine months ended September 30, 2004
included $59.7 million in proceeds from the sale of three real estate properties and a residual
property interest and $16.7 million from the disposal of other property, plant and equipment.
During 2004, $33.0 million was used to acquire Trend Western Technical Corporation. Capital
expenditures, primarily for ongoing renewal and replacement in the construction equipment
operations, including hurricane relief contracts in the United States and operations in Iraq and
Eastern Europe were $145.3 million in the nine months ended September 30, 2005 compared with $68.8
million in the same period of 2004. A joint-venture entity that will maintain telecommunications
facilities for the London Underground was funded during 2005, resulting in a cash investment of
$13.6 million.
Cash utilized by financing activities in the first nine months of 2005 included a $129.9 million
repayment of commercial paper. Partially offsetting this cash outflow were proceeds from the
issuance of 758,367 shares of common stock for $41.8 million. During 2004, net proceeds of $322.5
million were realized from the issuance of convertible senior notes. A portion of the proceeds
from this issuance was used to repay $100 million of outstanding debt on the companys Aliso Viejo,
California facilities and $121.5 million of commercial paper. Also impacting cash flows in the
first nine months of both 2005 and 2004 was $40.2 million and $33.7 million, respectively, in cash
received from the exercise of stock options. Cash utilized for the payment of dividends ($0.48 per
share) in the nine months ended September 30, 2005 and 2004 was $41.5 million and $40.0 million,
respectively. The companys total debt to total capitalization (debt-to-capital) ratio at
September 30, 2005 was 18.5 percent compared with 26.3 percent at December 31, 2004.
Liquidity is provided by cash generated from operations, advance billings on contracts in progress
and access to financial markets. As customer advances are reduced through use in project execution
and if not replaced by advances on new projects, the companys cash position would be reduced. The
27
requirements for operating liquidity could result in the need for short-term borrowings. For the
next 12 months, cash generated from operations supplemented as necessary by borrowings under credit
facilities and the issuance of debt or equity securities are expected to be sufficient to fund
operations. The total cost of acquisition and construction of the new corporate headquarters in the
Dallas/Fort Worth metropolitan area are expected to be approximately $60 million, and will be
funded from available cash resources over the next six to nine months. As of September 30, 2005,
approximately $9 million of the cost of the new corporate headquarters had been paid.
Off-Balance Sheet Arrangements
The company maintains a variety of commercial commitments that are generally made available to
provide support for various commercial provisions in its engineering and construction contracts.
The company has $761 million in committed and uncommitted lines of credit to support letters of
credit. Letters of credit are provided to clients in the ordinary course of business in lieu of
retention or for performance and completion guarantees on engineering and construction contracts.
As of September 30, 2005, the company had utilized $309 million of its letter of credit capacity
compared with $392 million as of December 31, 2004. The company also posts surety bonds primarily
on state and local government projects to guarantee its performance on contracts.
In the ordinary course of business, the company enters into various agreements providing financial
or performance assurances to clients on behalf of certain unconsolidated subsidiaries, joint
ventures and for other jointly executed contracts. These agreements are entered into primarily to
support the project execution commitments of these entities. The guarantees have various expiration
dates ranging from mechanical completion of the facilities being constructed to a period extending
beyond contract completion in certain circumstances. The maximum potential payment amount of an
outstanding performance guarantee is the remaining cost of work to be performed by or on behalf of
third parties under engineering and construction contracts. In most cases any amounts expended on
behalf of a partner or joint venture participant pursuant to performance guarantees would be
recovered from the client or other third party for work performed in the ordinary course of
contract execution. As of September 30, 2005, the amount of guarantees outstanding measured on
this basis increased to $2.4 billion compared with $1.8 billion as of December 31, 2004 as the
principal result of a new transportation infrastructure joint-venture project.
The company has a joint venture arrangement that will design, build, finance and maintain an
aircraft refueling facility at a United States Air Force base in Qatar for the Defense Energy
Support Center, an agency of the Department of Defense. The company has a 27.5 percent interest in
the joint venture company. On April 29, 2005, the joint venture entered into an agreement for
project financing which includes a joint and several project completion guarantee by the members of
the joint venture. The maximum potential amount of future payments that could be required under
the guarantee is $76.5 million, the maximum principal amount available under the financing
arrangement, plus any accrued interest.
During the third quarter of 2005 the company was awarded a $524 million Infrastructure project to
design, build and finance a new telecommunications system throughout Englands motorways. The
project will be executed through a joint venture in which the company owns a 45 percent interest.
The joint venture will borrow approximately $260 million on a non-recourse basis which along with
partner capital contributions totaling approximately $40 million will be used to construct the
upgraded telecommunications infrastructure. During construction the existing telecommunications
system will be operated and maintained. Upon completion of the upgrade the entire system will be
operated and maintained under a services agreement extending through
2016. The company is currently evaluating the joint venture
arrangement and will determine any additional reporting
responsibilities with respect to its participation in the fourth
quarter.
Financial guarantees, made in the ordinary course of business on behalf of clients and others in
certain limited circumstances, are entered into with financial institutions and other credit
grantors and generally obligate the company to make payment in the event of a default by the
borrower. Most arrangements require the borrower to pledge collateral in the form of property,
plant and equipment which is deemed adequate to recover amounts the company might be required to
pay. As of September 30, 2005, no material changes to financial guarantees of the debt of third
parties had occurred since the filing of the companys December 31, 2004 annual report on Form
10-K.
28
Financial Instruments
The company utilizes forward exchange contracts to hedge foreign currency transactions entered into
in the ordinary course of business and not to engage in currency speculation. At September 30,
2005, the company had forward foreign exchange contracts of less than 17 months duration to
exchange major world currencies for U.S. dollars. The total gross notional amount of these
contracts at September 30, 2005 was $48 million.
Item 3. Quantitative and Qualitative Disclosures about Market Risk
There have been no material changes on this matter in the first nine months of 2005. Accordingly,
the disclosures provided in the Annual Report on Form 10-K for the year ended December 31, 2004
remain current.
Item 4. Controls and Procedures
Evaluation of Disclosure Controls and Procedures
As of the end of the period covered by this report, under the supervision and with the
participation of our management, including our chief executive officer and chief financial officer,
we conducted an evaluation of the effectiveness of the design and operation of our disclosure
controls and procedures. Based on this evaluation, our chief executive officer and chief financial
officer concluded that, as of the end of the period covered by this report, our disclosure controls
and procedures were effective in alerting them on a timely basis to information relating to the
company that is required to be included in our periodic reports filed with the SEC.
To maintain a cost-effective controls structure, management necessarily applied its judgment in
assessing the costs and benefits of such controls and procedures, which, by their nature, can only
provide reasonable assurance that our managements control objectives are met. In addition, the
design of any system of control is based upon certain assumptions about the likelihood of future
events, and there can be no assurance that any design will succeed in achieving its stated goals
under all future events, no matter how remote.
Changes in Internal Control over Financial Reporting
There were no changes to our internal control over financial reporting that occurred during the
three months ended on the date of this report that have materially affected, or are reasonably
likely to materially affect, our internal control over financial reporting.
29
FLUOR CORPORATION
CHANGES IN CONSOLIDATED BACKLOG
Three and Nine Months Ended September 30, 2005 and 2004
UNAUDITED
| |
|
|
|
|
|
|
|
|
| |
|
Three Months Ended |
|
| |
|
September 30 |
|
| $ in millions |
|
2005 |
|
|
2004 |
|
| |
|
|
Backlog beginning of period |
|
$ |
15,666.4 |
|
|
$ |
12,919.4 |
|
New awards |
|
|
2,533.3 |
|
|
|
3,225.4 |
|
Adjustments and cancellations, net |
|
|
(195.0 |
) |
|
|
(86.3 |
) |
Work performed |
|
|
(3,342.2 |
) |
|
|
(2,312.6 |
) |
| |
|
|
Backlog end of period |
|
$ |
14,662.5 |
|
|
$ |
13,745.9 |
|
| |
|
|
| |
|
|
|
|
|
|
|
|
| |
|
Nine Months Ended |
|
| |
|
September 30 |
|
| $ in millions |
|
2005 |
|
|
2004 |
|
| |
|
|
Backlog beginning of period |
|
$ |
14,765.8 |
|
|
$ |
10,607.1 |
|
New awards |
|
|
9,114.3 |
|
|
|
9,659.6 |
|
Adjustments and cancellations, net |
|
|
(211.5 |
) |
|
|
(21.9 |
) |
Work performed |
|
|
(9,006.1 |
) |
|
|
(6,498.9 |
) |
| |
|
|
Backlog end of period |
|
$ |
14,662.5 |
|
|
$ |
13,745.9 |
|
| |
|
|
30
PART II: OTHER INFORMATION
Item 1. Legal Proceedings
Fluor and its subsidiaries, incidental to their normal business activities, are parties to a number
of legal proceedings and other matters in various stages of development. While we cannot predict
the outcome of these proceedings, in our opinion and based on reports of counsel, any liability
arising from these matters individually and in the aggregate are not expected to have a material
adverse effect upon the consolidated financial position, or the results of operations of the
company, after giving effect to provisions already recorded.
See the section entitled Results of Operations Oil & Gas in Part I, Item 2 in Managements
Discussion and Analysis of Financial Condition and Results of Operations, above for a discussion of
the settlement of claims relating to the Hamaca Crude Upgrader project.
Item 2. Unregistered Sales of Equity Securities and Use of Proceeds
| (c) |
|
The following table provides information about purchases by the company during the quarter
ended September 30, 2005 of equity securities that are registered by the company pursuant to
Section 12 of the Exchange Act: |
Issuer Purchases of Equity Securities
(in thousands, except per share data)
| |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
| |
|
|
|
|
|
|
|
|
|
Total Number of |
|
|
Maximum |
|
| |
|
|
|
|
|
|
|
|
|
Shares |
|
|
Number of |
|
| |
|
|
|
|
|
|
|
|
|
Purchased as |
|
|
Shares that May |
|
| |
|
Total |
|
|
|
|
|
|
Part of Publicly |
|
|
Yet Be |
|
| |
|
Number of |
|
|
Average |
|
|
Announced |
|
|
Purchased Under |
|
| |
|
Shares |
|
|
Price Paid |
|
|
Plans or |
|
|
the Plans or |
|
| Period |
|
Purchased(1) |
|
|
per Share |
|
|
Programs |
|
|
Program(2) |
|
| |
July 1, 2005 July 31, 2005 |
|
|
0 |
|
|
$ |
0.00 |
|
|
|
N/A |
|
|
|
4,141 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
August 1, 2005 August 31, 2005 |
|
|
0 |
|
|
|
0.00 |
|
|
|
N/A |
|
|
|
4,141 |
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
September 1, 2005 September 30, 2005 |
|
|
16 |
|
|
|
60.93 |
|
|
|
N/A |
|
|
|
4,141 |
|
|
|
|
| (1) |
|
Shares cancelled as payment for statutory withholding taxes upon the vesting of
restricted stock issued pursuant to equity based employee benefit plans. |
| |
| (2) |
|
On September 20, 2001, the company announced that the Board of Directors had
approved the repurchase of up to five million shares of our common stock. That authorization
is ongoing and does not have an expiration date. |
31
Item 6. Exhibits
| |
|
|
| Exhibit |
|
Description |
3.1
|
|
Amended and Restated Certificate of Incorporation of the registrant (1) |
|
|
|
3.2
|
|
Amended and Restated Bylaws of the registrant (12) |
|
|
|
4.1
|
|
Indenture between Fluor Corporation and Bank of New York, as trustee dated as of
February 17, 2004 (2) |
|
|
|
10.1
|
|
Distribution Agreement between the registrant and Fluor Corporation (renamed Massey
Energy Company) (3) |
|
|
|
10.2
|
|
Tax Sharing Agreement between Fluor Corporation and A.T. Massey Coal Company,
Inc.(4) |
|
|
|
10.3
|
|
Special Retention Program, dated March 7, 2000, between Fluor Corporation and Alan L.
Boeckmann (1) |
|
|
|
10.4
|
|
Special Retention Program, dated September 12, 2000, between Fluor Corporation and
Mark A. Stevens (5) |
|
|
|
10.5
|
|
Fluor Corporation 2000 Executive Performance Incentive Plan as amended and restated
as of March 30, 2005 (12) |
|
|
|
10.6
|
|
Fluor Corporation 2000 Restricted Stock Plan for Non-Employee Directors (6) |
|
|
|
10.7
|
|
Fluor Corporation Executive Deferred Compensation Plan, as amended and restated
effective January 1, 2002 (7) |
|
|
|
10.8
|
|
Fluor Corporation Deferred Directors Fees Program, as amended and restated effective
January 1, 2002 (5) |
|
|
|
10.9
|
|
Directors Life Insurance Summary(1) |
|
|
|
10.10
|
|
Fluor Executives Supplemental Benefit Plan (1) |
|
|
|
10.11
|
|
Fluor Corporation Retirement Plan for Outside Directors (1) |
|
|
|
10.12
|
|
Executive Severance Plan (9) |
|
|
|
10.13
|
|
2001 Key Employee Performance Incentive Plan as amended and restated as of March 30,
2005 (12) |
|
|
|
10.14
|
|
2001 Fluor Stock Appreciation Rights Plan (7) |
|
|
|
10.15
|
|
Fluor Corporation 2003 Executive Performance Incentive Plan as amended and restated
as of March 30, 2005 (12) |
|
|
|
10.16
|
|
Form of Compensation Award Agreements for grants under the Fluor Corporation 2003
Executive Performance Incentive Plan (10) |
|
|
|
10.17
|
|
Code of Ethics and Business Conduct, as amended and restated (11) |
|
|
|
10.18
|
|
Offer of Employment Letter dated May 7, 2001 from Fluor Corporation to D. Michael
Steuert (11) |
|
|
|
10.19
|
|
Credit Agreement dated as of July 28, 2004 among Fluor Corporation, the lenders party
thereto from time to time, BNP Paribas, as Administrative Agent and an Issuing
Lender, and Bank of America, N.A. and Citicorp USA, Inc., as Co-Syndication Agents
(8) |
|
|
|
31.1
|
|
Certification of Chief Executive Officer pursuant to Rule 13a-14(a) or Rule 15d-14(a)
of the Securities Exchange Act of 1934 * |
|
|
|
31.2
|
|
Certification of Chief Financial Officer pursuant to Rule 13a-14(a) or Rule 15d-14(a)
of the Securities Exchange Act of 1934 * |
32
| |
|
|
| Exhibit |
|
Description |
32.1
|
|
Certification of Chief Executive Officer pursuant to Rule
13a-14(b) or Rule 15d-14(b) of the Securities Exchange Act of 1934
and 18 U.S.C. Section 1350 * |
|
|
|
32.2
|
|
Certification of Chief Financial Officer pursuant to Rule
13a-14(b) or Rule 15d-14(b) of the Securities Exchange Act of 1934
and 18 U.S.C. Section 1350 * |
|
|
|
| * |
|
New exhibit filed with this report. |
| |
| (1) |
|
Filed as the same numbered exhibit to the Registrants Registration
Statement on Form 10/A (Amendment No. 1) filed on November 22, 2000 and
incorporated herein by reference. |
| |
| (2) |
|
Filed as an exhibit to the Registrants report on Form 8-K filed on
February 17, 2004 incorporated herein by reference. |
| |
| (3) |
|
Filed as Exhibit 10.1 to the Registrants report on Form 8-K dated
December 7, 2000 and incorporated herein by reference. |
| |
| (4) |
|
Filed as Exhibit 10.2 to the Registrants report on Form 8-K dated
December 7, 2000 and incorporated herein by reference. |
| |
| (5) |
|
Filed as an exhibit to the Registrants report on Form 10-K filed on
March 31, 2003 and incorporated herein by reference. |
| |
| (6) |
|
Filed as Exhibit 10.2 to the Registrants report on Form 8-K dated
December 29, 2000 and incorporated herein by reference. |
| |
| (7) |
|
Filed as an exhibit to the Registrants report on Form 10-K filed on
March 21, 2002 and incorporated herein by reference. |
| |
| (8) |
|
Filed as Exhibit 10.18 to the Registrants report on Form 10-Q dated
August 9, 2004 and incorporated herein by reference. |
| |
| (9) |
|
Filed as an exhibit to the Registrants report on Form 8-K filed on
August 9, 2004 and incorporated herein by reference. |
| |
| (10) |
|
Filed as an exhibit to the Registrants report on Form 8-K filed on
November 9, 2004 and incorporated herein by reference. |
| |
| (11) |
|
Filed as an exhibit to the Registrants report on Form 10-K filed on
March 15, 2004 and incorporated herein by reference. |
| |
| (12) |
|
Filed as an exhibit to the Registrants report on Form 10-Q filed on
May 5, 2005 and incorporated herein by reference. |
33
SIGNATURES
Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly
caused this report to be signed on its behalf by the undersigned thereunto duly authorized.
| |
|
|
|
|
|
|
FLUOR CORPORATION |
|
|
|
|
|
|
|
Date: November 3, 2005
|
|
/s/ D. Michael Steuert |
|
|
|
|
|
|
|
|
|
D. Michael Steuert |
|
|
|
|
Senior Vice President and Chief Financial Officer |
|
|
|
|
|
|
|
Date: November 3, 2005
|
|
/s/ V. L. Prechtl |
|
|
|
|
|
|
|
|
|
V. L. Prechtl |
|
|
|
|
Vice President and Controller |
|
|
34
EXHIBIT INDEX
| |
|
|
| Exhibit |
|
Description |
3.1
|
|
Amended and Restated Certificate of Incorporation of the registrant (1) |
|
|
|
3.2
|
|
Amended and Restated Bylaws of the registrant (12) |
|
|
|
4.1
|
|
Indenture between Fluor Corporation and Bank of New York, as trustee dated as of February 17,
2004 (2) |
|
|
|
10.1
|
|
Distribution Agreement between the registrant and Fluor Corporation (renamed Massey Energy
Company) (3) |
|
|
|
10.2
|
|
Tax Sharing Agreement between Fluor Corporation and A.T. Massey Coal Company, Inc.(4) |
|
|
|
10.3
|
|
Special Retention Program, dated March 7, 2000, between Fluor Corporation and Alan L. Boeckmann
(1) |
|
|
|
10.4
|
|
Special Retention Program, dated September 12, 2000, between Fluor Corporation and Mark A.
Stevens (5) |
|
|
|
10.5
|
|
Fluor Corporation 2000 Executive Performance Incentive Plan as amended and restated as of March
30, 2005 (12) |
|
|
|
10.6
|
|
Fluor Corporation 2000 Restricted Stock Plan for Non-Employee Directors (6) |
|
|
|
10.7
|
|
Fluor Corporation Executive Deferred Compensation Plan, as amended and restated effective
January 1, 2002 (7) |
|
|
|
10.8
|
|
Fluor Corporation Deferred Directors Fees Program, as amended and restated effective January
1, 2002 (5) |
|
|
|
10.9
|
|
Directors Life Insurance Summary(1) |
|
|
|
10.10
|
|
Fluor Executives Supplemental Benefit Plan (1) |
|
|
|
10.11
|
|
Fluor Corporation Retirement Plan for Outside Directors (1) |
|
|
|
10.12
|
|
Executive Severance Plan (9) |
|
|
|
10.13
|
|
2001 Key Employee Performance Incentive Plan as amended and restated as of March 30, 2005
(12) |
|
|
|
10.14
|
|
2001 Fluor Stock Appreciation Rights Plan (7) |
|
|
|
10.15
|
|
Fluor Corporation 2003 Executive Performance Incentive Plan as amended and restated as of March
30, 2005 (12) |
|
|
|
10.16
|
|
Form of Compensation Award Agreements for grants under the Fluor Corporation 2003 Executive
Performance Incentive Plan (10) |
|
|
|
10.17
|
|
Code of Ethics and Business Conduct, as amended and restated (11) |
|
|
|
10.18
|
|
Offer of Employment Letter dated May 7, 2001 from Fluor Corporation to D. Michael Steuert
(11) |
|
|
|
10.19
|
|
Credit Agreement dated as of July 28, 2004 among Fluor Corporation, the lenders party thereto
from time to time, BNP Paribas, as Administrative Agent and an Issuing Lender, and Bank of
America, N.A. and Citicorp USA, Inc., as Co-Syndication Agents (8) |
35
| |
|
|
| Exhibit |
|
Description |
31.1
|
|
Certification of Chief Executive Officer pursuant to Rule
13a-14(a) or Rule 15d-14(a) of the Securities Exchange Act of 1934
* |
|
|
|
31.2
|
|
Certification of Chief Financial Officer pursuant to Rule
13a-14(a) or Rule 15d-14(a) of the Securities Exchange Act of 1934
* |
|
|
|
32.1
|
|
Certification of Chief Executive Officer pursuant to Rule
13a-14(b) or Rule 15d-14(b) of the Securities Exchange Act of 1934
and 18 U.S.C. Section 1350 * |
|
|
|
32.2
|
|
Certification of Chief Financial Officer pursuant to Rule
13a-14(b) or Rule 15d-14(b) of the Securities Exchange Act of 1934
and 18 U.S.C. Section 1350 * |
|
|
|
| * |
|
New exhibit filed with this report. |
| |
| (1) |
|
Filed as the same numbered exhibit to the Registrants Registration Statement on
Form 10/A (Amendment No. 1) filed on November 22, 2000 and incorporated herein by
reference. |
| |
| (2) |
|
Filed as an exhibit to the Registrants report on Form 8-K filed on February 17,
2004 incorporated herein by reference. |
| |
| (3) |
|
Filed as Exhibit 10.1 to the Registrants report on Form 8-K dated December 7, 2000
and incorporated herein by reference. |
| |
| (4) |
|
Filed as Exhibit 10.2 to the Registrants report on Form 8-K dated December 7, 2000
and incorporated herein by reference. |
| |
| (5) |
|
Filed as an exhibit to the Registrants report on Form 10-K filed on March 31, 2003
and incorporated herein by reference. |
| |
| (6) |
|
Filed as Exhibit 10.2 to the Registrants report on Form 8-K dated December 29, 2000
and incorporated herein by reference. |
| |
| (7) |
|
Filed as an exhibit to the Registrants report on Form 10-K filed on March 21, 2002
and incorporated herein by reference. |
| |
| (8) |
|
Filed as Exhibit 10.18 to the Registrants report on Form 10-Q dated August 9, 2004
and incorporated herein by reference. |
| |
| (9) |
|
Filed as an exhibit to the Registrants report on Form 8-K filed on August 9, 2004
incorporated herein by reference. |
| |
| (10) |
|
Filed as an exhibit to the Registrants report on Form 8-K filed on November 9,
2004 incorporated herein by reference. |
| |
| (11) |
|
Filed as an exhibit to the Registrants report on Form 10-K filed on March 15, 2004
and incorporated herein by reference. |
| |
| (12) |
|
Filed as an exhibit to the Registrants report on Form 10-Q filed on May 5, 2005
and incorporated herein by reference. |
36
Exhibit 31.1
Exhibit 31.1
CERTIFICATION OF CHIEF EXECUTIVE OFFICER
PURSUANT TO RULE 13a-14(a) OR RULE 15d-14(a)
OF THE SECURITIES EXCHANGE ACT OF 1934
I, Alan L. Boeckmann, certify that:
1. I have reviewed this quarterly report on Form 10-Q of Fluor Corporation;
2. Based on my knowledge, this report does not contain any untrue statement of a material
fact or omit to state a material fact necessary to make the statements made, in light of the
circumstances under which such statements were made, not misleading with respect to the period
covered by this report;
3. Based on my knowledge, the financial statements, and other financial information included
in this report, fairly present in all material respects the financial condition, results of
operations and cash flows of the registrant as of, and for, the periods presented in this report;
4. The registrants other certifying officer(s) and I are responsible for establishing and
maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and
15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules
13a-15(f) and 15d-15(f)) for the registrant and have:
a) Designed such disclosure controls and procedures, or caused such disclosure controls and
procedures to be designed under our supervision, to ensure that material information relating to
the registrant, including its consolidated subsidiaries, is made known to us by others within
those entities, particularly during the period in which this report is being prepared;
b) Designed such internal control over financial reporting, or caused such internal control
over financial reporting to be designed under our supervision, to provide reasonable assurance
regarding the reliability of financial reporting and the preparation of financial statements for
external purposes in accordance with generally accepted accounting principles;
c) Evaluated the effectiveness of the registrants disclosure controls and procedures and
presented in this report our conclusions about the effectiveness of the disclosure controls and
procedures, as of the end of the period covered by this report based on such evaluation; and
d) Disclosed in this report any change in the registrants internal control over financial
reporting that occurred during the registrants most recent fiscal quarter (the registrants
fourth fiscal quarter in the case of an annual report) that has materially affected, or is
reasonably likely to materially affect, the registrants internal control over financial
reporting; and
5. The registrants other certifying officer(s) and I have disclosed, based on our most
recent evaluation of internal control over financial reporting, to the registrants auditors and
the audit committee of registrants board of directors (or persons performing the equivalent
functions):
a) All significant deficiencies and material weaknesses in the design or operation of
internal control over financial reporting which are reasonably likely to adversely affect the
registrants ability to record, process, summarize and report financial information; and
b) Any fraud, whether or not material, that involves management or other employees who have
a significant role in the registrants internal control over financial reporting.
| |
|
|
|
|
| |
|
|
| Date: November 3, 2005 |
By: |
/s/ Alan L. Boeckmann
|
|
| |
|
Alan L. Boeckmann, |
|
| |
|
Chairman of the Board and
Chief Executive Officer |
|
| |
37
Exhibit 31.2
Exhibit 31.2
CERTIFICATION OF CHIEF FINANCIAL OFFICER
PURSUANT TO RULE 13a-14(a) OR RULE 15d-14(a)
OF THE SECURITIES EXCHANGE ACT OF 1934
I, D. Michael Steuert, certify that:
1. I have reviewed this quarterly report on Form 10-Q of Fluor Corporation;
2. Based on my knowledge, this report does not contain any untrue statement of a material
fact or omit to state a material fact necessary to make the statements made, in light of the
circumstances under which such statements were made, not misleading with respect to the period
covered by this report;
3. Based on my knowledge, the financial statements, and other financial information included
in this report, fairly present in all material respects the financial condition, results of
operations and cash flows of the registrant as of, and for, the periods presented in this report;
4. The registrants other certifying officer(s) and I are responsible for establishing and
maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and
15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules
13a-15(f) and 15d-15(f)) for the registrant and have:
a) Designed such disclosure controls and procedures, or caused such disclosure controls and
procedures to be designed under our supervision, to ensure that material information relating to
the registrant, including its consolidated subsidiaries, is made known to us by others within
those entities, particularly during the period in which this report is being prepared;
b) Designed such internal control over financial reporting, or caused such internal control
over financial reporting to be designed under our supervision, to provide reasonable assurance
regarding the reliability of financial reporting and the preparation of financial statements for
external purposes in accordance with generally accepted accounting principles;
c) Evaluated the effectiveness of the registrants disclosure controls and procedures and
presented in this report our conclusions about the effectiveness of the disclosure controls and
procedures, as of the end of the period covered by this report based on such evaluation; and
d) Disclosed in this report any change in the registrants internal control over financial
reporting that occurred during the registrants most recent fiscal quarter (the registrants
fourth fiscal quarter in the case of an annual report) that has materially affected, or is
reasonably likely to materially affect, the registrants internal control over financial
reporting; and
5. The registrants other certifying officer(s) and I have disclosed, based on our most
recent evaluation of internal control over financial reporting, to the registrants auditors and
the audit committee of registrants board of directors (or persons performing the equivalent
functions):
a) All significant deficiencies and material weaknesses in the design or operation of
internal control over financial reporting which are reasonably likely to adversely affect the
registrants ability to record, process, summarize and report financial information; and
b) Any fraud, whether or not material, that involves management or other employees who have
a significant role in the registrants internal control over financial reporting.
| |
|
|
|
|
| |
|
|
| Date: November 3, 2005 |
By: |
/s/ D. Michael Steuert
|
|
| |
|
D. Michael Steuert, |
|
| |
|
Senior Vice President and
Chief Financial Officer |
|
| |
38
Exhibit 32.1
Exhibit 32.1
CERTIFICATION OF CHIEF EXECUTIVE OFFICER
PURSUANT TO RULE 13a-14(b) OR RULE 15d-14(b)
OF THE SECURITIES EXCHANGE ACT OF 1934
AND 18 U.S.C. SECTION 1350
In connection with the Quarterly Report of Fluor Corporation (the Company) on Form 10-Q for
the period ended September 30, 2005, as filed with the Securities and Exchange Commission on the
date hereof (the Report), I, Alan L. Boeckmann, Chairman and Chief Executive Officer of the
Company, certify, for purposes of 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the
Sarbanes-Oxley Act of 2002, that to my knowledge:
| |
|
|
the Report fully complies with the requirements of Section 13(a) or 15(d) of the
Securities Exchange Act of 1934, as amended; and |
| |
| |
|
|
the information contained in the Report fairly presents, in all material respects,
the financial condition and results of operations of the Company. |
| |
|
|
|
|
| |
|
|
| Date: November 3, 2005 |
By: |
/s/ Alan L. Boeckmann
|
|
| |
|
Alan L. Boeckmann, |
|
| |
|
Chairman of the Board and
Chief Executive Officer |
|
| |
A signed original of this written statement required by 18 U.S.C. Section 1350 has been provided to
the Company and will be retained by the Company and furnished to the Securities and Exchange
Commission or its staff upon request.
39
Exhibit 32.2
Exhibit 32.2
CERTIFICATION OF CHIEF FINANCIAL OFFICER
PURSUANT TO RULE 13a-14(b) OR RULE 15d-14(b)
OF THE SECURITIES EXCHANGE ACT OF 1934
AND 18 U.S.C. SECTION 1350
In connection with the Quarterly Report of Fluor Corporation (the Company) on Form 10-Q for
the period ended September 30, 2005, as filed with the Securities and Exchange Commission on the
date hereof (the Report), I, D. Michael Steuert, Senior Vice President and Chief Financial
Officer of the Company, certify, for purposes of 18 U.S.C. Section 1350, as adopted pursuant to
Section 906 of the Sarbanes-Oxley Act of 2002, that to my knowledge:
| |
|
|
the Report fully complies with the requirements of Section 13(a) or 15(d) of the
Securities Exchange Act of 1934, as amended; and |
| |
| |
|
|
the information contained in the Report fairly presents, in all material respects,
the financial condition and results of operations of the Company. |
| |
|
|
|
|
| |
|
|
| Date: November 3, 2005 |
By: |
/s/ D. Michael Steuert
|
|
| |
|
D. Michael Steuert, |
|
| |
|
Senior Vice President and
Chief Financial Officer |
|
| |
A signed original of this written statement required by 18 U.S.C. Section 1350 has been provided to
the Company and will be retained by the Company and furnished to the Securities and Exchange
Commission or its staff upon request.
40